HomeMy WebLinkAboutCity of Tamarac Resolution R-2022-079 Maceda Contractors LLC Agmt for Dog Park RenovationTemp. Reso. #13810
July 13, 2022
Page 1 of 4
CITY OF TAMARAC, FLORIDA
RESOLUTION NO. R-2022-071
A RESOLUTION OF THE CITY COMMISSION OF THE
CITY OF TAMARAC, FLORIDA, AWARDING ITB 22-11 B
TAMARAC DOG PARK RENOVATION PROJECT TO
MACEDA CONTRACTORS, LLC AND APPROVING THE
EXECUTION OF AN AGREEMENT BETWEEN THE CITY
OF TAMARAC AND MACEDA CONTRACTORS, LLC AT A
COST NOT TO EXCEED $175,697.00 AND A
CONTINGENCY ALLOWANCE OF $17,570.00 FOR A
TOTAL PROJECT BUDGET OF $193,267.00. APPROVING
FUNDING FROM THE APPROPRIATE CAPITAL
IMPROVEMENT ACCOUNTS; PROVIDING FOR
CONFLICTS; PROVIDING FOR SEVERABILITY; AND
PROVIDING AN EFFECTIVE DATE.
WHEREAS, Florida Statutes provide that municipalities shall have the
governmental, corporate, and proprietary powers to enable them to conduct municipal
government, perform municipal functions and render municipal service, and exercise
any power for municipal purposes, except when expressly prohibited by law; and
WHEREAS, Article IV, Section 4.07 of the City Charter of the City of Tamarac
("City) empowers the City to adopt, amend or repeal such ordinances and resolutions as
may be required for the proper governing of the City ; and
WHEREAS, the City of Tamarac desires to provide its residents and visitors a
higher level of service by enhancing and improving its parks and surrounding
environment; and
WHEREAS, Tamarac Dog Park, AKA Gary B Jones Park for People and Pups
Temp. Reso. #13810
July 13, 2022
Page 2 of 4
Park is located at 8101 Southgate Boulevard, in the City of Tamarac, Florida; and
WHEREAS, the City published Invitation for a Bid ITB# 22-11 B for the Tamarac
Dog Park Renovation Project on April 26, 2022 (Project); and
WHEREAS, the City received six (6) responses from firms including Maceda
Contractors, LLC,(Maceda) and
WHEREAS, a copy of the ranking sheet is attached as "Exhibit 1"; and
WHEREAS, The Purchasing Division determined that the response submitted by
Maceda was the lowest responsive and responsible bidder and best able to meet the
needs of the City; and
WHEREAS, the City of Tamarac has negotiated an agreement attached as
Exhibit 2" with Maceda for the Project at a cost not to exceed $193,267.00 (Agreement);
and
WHEREAS, a contingency allowance in the amount of $17,570.00 is added to
this Project to be used only on an as needed basis; and
WHEREAS, it is the recommendation of the Director of Public Services, the
Director of Parks and Recreation, and the Purchasing and Contracts Manager that the
contract for Tamarac Dog Park Renovation Project be awarded to MACEDA
CONTRACTORS, LLC, and
WHEREAS, the City Commission of the City of Tamarac, Florida, deems it to be
in the best interest of the business owners, residents, and visitors of the City of
Tamarac to enter into the Agreement with Maceda for the Project, at a cost not to
exceed $175,697.00, amount of $17,570.00, for a total budget of $193,267.00.
Temp. Reso. #13810
July 13, 2022
Page 3 of 4
NOW, THEREFORE, BE IT RESOLVED BY THE CITY COMMISSION OF THE
CITY OF TAMARAC, FLORIDA THAT:
Section 1: The foregoing recitals are true and correct and hereby adopted as
the legislative and administrative findings of the City Commission; all exhibits attached
hereto are incorporated herein and made a specific part of this Resolution.
Section 2: The City Commission awards ITB No.22-11 B to and approves an
Agreement between the City of Tamarac and Maceda Contractors, LLC, for the
Tamarac Dog Park Renovation Project in the amount of $175,697.00 and a contingency
allowance of $17,570.00 for a total budget of $193,267.00. The appropriate City
Officials are authorized to execute the Agreement, expend budgeted funds, make
changes to the scope of the Project, issue Change Orders, and close the contract
award including, but not limited to, making final payment and release of bonds when the
work has been successfully completed within the terms and conditions of the
Agreement pursuant to Section 6-1470) of the City Code.
Section 3: All resolutions or parts of resolutions in conflict herewith are hereby
repealed to the extent of such conflict.
Section 4: If any clause, section, other part, or application of this Resolution is
held by any court of competent jurisdiction to be unconstitutional or invalid, in part or
application, it shall not affect the validity of the remaining portions or applications of this
Resolution.
Section 5: This Resolution shall become effective immediately upon adoption.
PASSED, ADOPTED AND APPROVED this 13t' day of July 2022.
ATTEST:
KIMBERL_ DILLON, CMC
ACTING CITY CLERK
Temp. Reso. #13810
July 13, 2022
Page 4 of 4
/Xitz //1 :� .7 (� - ___
MICH,tLLE J. GOMEZ
MAYOR
RECORD OF COMMISSION VOT
MAYOR GOMEZ:
DIST 1: COMM. BOLTON
DIST 2: V/M GELIN
DIST 3: COMM. VILLALOBOS
DIST 4: COMM. PLACKO
APPROVED AS TO FORM AND LEGAL SUFFICIENCY FOR
THE USK AND RELIANCE OF THE CITY OF TAMARAC ONLY.
JP'FIN �. HRRIN, J
CITY A11TORNEY
TAMARAC
City of Tamarac The City For Your Life Purchasing and Contracts Division
CONSTRUCTION AGREEMENT
BETWEEN THE CITY OF TAMARAC
AND
Maceda Contractors. LLC.
THIS AGREEMENT is made and entered into this I- day of; L%� 20� by and between
the City of Tamarac, a municipal corporation with principal;[ ffi es cated at 7525 N.W. 88th Ave.,
Tamarac, FL 33321 (the "CITY") and Maceda Contractors, LL . with principal offices located at 5030
SW 173rd Road, Southwest Ranches, Florida 33331 (the "Contractor") to provide for construction
services to renovate the Tamarac Dog Park.
Now therefore, in consideration of the mutual covenants hereinafter set forth, the City and Contractor
agree as follows:
1. THE CONTRACT DOCUMENTS
The Contract Documents consist of this Agreement, Bid Document No. 22-11 B for "Dog Park
Renovation Project", issued by the City of Tamarac on April 26, 2022 including all conditions
therein, (General Terms and Conditions, Special Conditions and/or Special Provisions,
Instructions to Bidder's), drawings and/or schematic plans, Technical Specifications, all
addenda, the Contractor's Bid response dated May 26, 2022, and all modifications issued after
execution of this Agreement. These contract documents form the Agreement, and all are as
fully a part of the Agreement as if attached to this Agreement or repeated therein. In the event
that there is a conflict between Bid 22-11 B for "Dog Park Renovation Project" as issued by
City, and the contractor's bid response; Bid 22-11 B for "Dog Park Renovation Project" as
issued by City shall take precedence over the contractor's bid response. Furthermore, in the
event of a conflict between this document and any other Contract Documents, this Agreement
shall prevail.
2. THE WORK
2.1. The Contractor shall perform all work for the City required by the contract documents
as set forth below:
2.1.1 Contractor shall furnish all labor, materials, and equipment necessary to
complete the scope of work, as outlined in the contract documents including all
Addendums, Exhibits, Attachments and Appendices.
2.1.2 Contractor shall supervise the work force to ensure that all workers conduct
themselves and perform their work in a safe and professional manner.
Contractor shall comply with all OSHA safety rules and regulations in the
operation of equipment and in the performance of the work. Contractor shall at
all times have a competent field supervisor on the job site to enforce these
policies and procedures at the Contractor's expense.
2.1.3 Contractor shall provide the City with seventy-two (72) hours written notice prior
to the beginning of work under this Agreement and prior to any schedule change
with the exception of changes caused by inclement weather.
2.1.4 Contractor shall comply with any and all Federal, State, and local laws and
regulations now in effect, or hereinafter enacted during the term of this
Agreement, which are applicable to the Contractor, its employees, agents or
subcontractors, if any, with respect to the work and services described herein.
TAMARAC
City of Tamarac The City For Your Life Purchasing and Contracts Division
3. INSURANCE
3.1. Contractor shall obtain at Contractor's expense all necessary insurance in such form
and amount as specified in the original bid document or as required by the City's Risk
and Safety Manager before beginning work under this Agreement including, but not
limited to, Workers' Compensation, Commercial General Liability, Builder's Risk and all
other insurance as required by the City, including Professional Liability when
appropriate. Contractor shall maintain such insurance in full force and effect during the
life of this Agreement. Contractor shall provide to the City's Risk and Safety Manager
certificates of all insurances required under this section prior to beginning any work
under this Agreement. The Contractor will ensure that all subcontractors comply with
the above guidelines and will retain all necessary insurance in force throughout the
term of this agreement.
3.2. Contractor shall indemnify and hold the City harmless for any damages resulting from
failure of the Contractor to take out and maintain such insurance. Contractor's Liability
Insurance policies shall be endorsed to add the City as an additional insured.
Contractor shall be responsible for payment of all deductibles and self-insurance
retentions on Contractor's Liability Insurance policies. The following are required types
and minimum limits of insurance coverage, which the Bidder agrees to maintain during
the term of this contract:
• General Liability - $1 M/$2M
• Automobile— $1 M/$1 M
• Workers Comp — Statutory
4. TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION
4.1 The work to be performed under this Agreement shall be commenced after City
execution of the Agreement and not later than ten (10) days after the date that
Contractor receives the City's Notice to Proceed. The work shall be completed within
Two Hundred Seventy (270) Calendar days for Final Completion from issuance of
City's Notice to Proceed, subject to any permitted extensions of time under the Contract
Documents. The work under this agreement shall be substantially complete (i.e.
Substantial Completion) within Two Hundred Twenty Five (225) calendar days from
issuance of City's Notice to Proceed.
4.2 During the pre -construction portion of the work hereunder, the parties agree to work
diligently and in good faith in performing their obligations hereunder, so that all required
permits for the construction portion of the work may be obtained by the Contractor in
accordance with the Schedule included in the Contract Documents. In the event that
any delays in the pre -construction or construction portion of the work occur, despite the
diligent efforts of the parties hereto, and such delays are the result of force majeure or
are otherwise outside of the control of either party hereto, then the parties shall agree
on an equitable extension of the time for substantial completion hereunder.
5. CONTRACT SUM
The Contract Sum for the above work is a "not to exceed" total of One Hundred Seventy Five
Thousand, Six Hundred and Ninety Seven Dollars and Zero Cents ($175,697.00).
22-'1 18 — Log Park Renovation
City of Tamarac
6. PAYMENTS
TAMARAC
The City For Your Life
Purchasing and Contracts Division
Payment will be made monthly for work that has been completed, inspected and properly
invoiced. A retainage of five percent (5%) will be deducted from each monthly payment through
project completion, upon City review and approval. Retainage monies will be released upon
satisfactory completion and final inspection of the specific work order. Invoices must bear the
bid number, project name, project number, and purchase order number. The City has up to
twenty-five (25) business days to review, approve and pay all invoices after receipt. The
Contractor shall invoice the City and provide a written request to the City to commence the
one-year warranty period. All necessary Release of Liens and Affidavits shall be processed
before the warranty period. All payments shall be governed by the Florida Prompt Payment
Act, F.S., Part VII, Chapter 218.
7. REMEDIES
7.1 Damages: The City reserves the right to recover any ascertainable actual damages
incurred as a result of the failure of the Contractor to perform in accordance with the
requirements of this Agreement, or for losses sustained by the City resultant from the
Contractor's failure to perform in accordance with the requirements of this Agreement.
7.2 Correction of Work: If, in the judgment of the City, work provided by the Contractor does
not conform to the requirements of this Agreement, or if the work exhibits poor
workmanship, the City reserves the right to require that the Contractor correct all
deficiencies in the work to bring the work into conformance without additional cost to
the City, and / or replace any personnel who fail to perform in accordance with the
requirements of this Agreement. Correction of all deficiencies shall not relieve the
Contractor of its duties and obligations under this agreement, in meeting all project
requirements and objectives including but not limited to achieving project milestones
(Substantial and Final Completion) in accordance with the Contract Documents. The
City shall be the sole judge of non-conformance and the quality of workmanship, and
any impact it may have on the Project Schedule.
8. CHANGE ORDERS
8.1 All Change Orders shall include a maximum Overhead and Profit, not to exceed five
percent (5%) and five percent (5%) respectively.
8.2 Without invalidating the contract, without any monetary compensation, and without
notice to any surety, the City reserves and shall have the right to make increases,
decreases or other changes to the work as may be considered necessary or desirable
to complete the proposed construction in a satisfactory manner. The Contractor shall
not start work pursuant to a change order until the change order setting forth the
adjustments is approved by the City and executed by the City and Contractor. Once
the change order is so approved, the Contractor shall promptly proceed with the work.
8.3 The Contract Price constitutes the total compensation (subject to authorized
adjustments, if applicable) payable to the Contractor for performing the work. All duties,
responsibilities and obligations assigned to or undertaken by the Contractor shall be at
Contractor's expense without change in the Contract Price or Time except as approved
in writing by the City.
8.4 The Contract Price and/or Time may only be changed by a Change Order. A fully
executed change order for any extra work must exist before such extra work is begun.
Any claim for an increase or decrease in the Contract Price shall be based on written
notice delivered by the party making the claim to the other party promptly (but in no
event later than 15 days) after the occurrence of the event giving rise to the claim and
22-11B - Dog Park Renovation Protect
TAMARAC
City of Tamarac The City For Your Life Purchasing and Contracts Division
stating the general nature of the claim. The amount of the claim with supporting data
shall be delivered (unless the City allows an additional period of time to ascertain more
accurate data in support of the claim) and shall be accompanied by claimant's written
statement that the amount claimed covers all known amounts to which the claimant is
entitled as a result of the occurrence of said event. No claim for an adjustment in the
Contract Price will be valid if not submitted in accordance with this Paragraph.
8.5 The Contract Time may only be changed by a Change Order. A fully executed change
order must exist prior to extension of the contract time.
8.6 Any claim for an extension of the Contract Time shall be based on written notice
delivered by the party making the claim to the other party no later than fifteen (15) days
after the occurrence of the event giving rise to the claim. Notice of the extent of the
claim shall be delivered with supporting data and stating the general nature of the claim.
Contractor hereby agrees to waive rights to recover any lost time or incurred costs from
delays unless Contractor has given the notice and the supporting data required by this
Paragraph.
8.7 Extensions of time shall be considered and will be based solely upon the effect of
delays to the work as a whole. Extensions of time shall not be granted for delays to the
work, unless the Contractor can clearly demonstrate that such delays did or will, in fact,
delay the progress of work as a whole. Time extensions shall not be allowed for delays
to parts of the work that are not on the critical path of the project schedule. Time
extensions shall not be granted until all float or contingency time, at the time of delay,
available to absorb specific delays and associated impacts is used.
8.8 In the event satisfactory adjustment cannot be reached by City and Contractor for any
item requiring a change in the contract, and a change order has not been issued, City
reserves the right at its sole option to terminate the contract as it applies to these items
in question and make such arrangements as City deems necessary to complete the
work. The cost borne by the City to complete the work shall be levied against the
Contractor including applicable mark-up of ten percent (10%) for overhead and
engineering costs. The cost of any work covered by a change order for an increase or
decrease in contract price shall be determined by mutual acceptance of a Guaranteed
Maximum Price by the City and Contractor. If notice of any change in the contract or
contract time is required to be given to a surety by the provisions of the bond, the giving
of such notice shall be the Contractor's responsibility, and the amount of each
applicable bond shall be adjusted accordingly. The Contractor shall furnish proof of
such adjustment to the City. Failure of the Contractor to obtain such approval from the
Surety may be a basis for termination of this Contract by the City.
9. LIQUIDATED DAMAGES
Project Substantial completion shall be within Two Hundred Twenty Five (225) calendar
days from Contractor's receipt of City's Notice to Proceed. Final Completion shall be
Two Hundred Seventy (270) calendar days from date of City's Notice to Proceed. All time
limits stated in the Contract Documents are of the essence of the Agreement. The parties
acknowledge that damages arising from delay in meeting these time limits are difficult or
impossible to ascertain. Therefore, the parties hereby agree that in the event that the
Contractor fails to meet the time limits, as may be extended by the City in accordance with the
terms of the Agreement or as otherwise provided in the Agreement, liquidated damages will
be assessed against Contractor in the amount of One Hundred Fifty Dollars and Zero Cents
150.00 for each calendar day beyond the time imposed until such work is Substantially
Complete. In the event of a delay beyond the time frame set forth in the Contract Documents
for Final Completion, liquidated damages will be assessed against the Contractor in the amount
2-*1 B — Do Park Reoovabon P"14s%C!
TAMA,RAC
City of Tamarac The City For Your Life Purchasing and Contrasts Division
- ..................... -- --- — -- -----
of Seventy -Five Dollars ($75.00) for each calendar day beyond the time frame set in the
Contract Documents until such work is completed.
10. NO DAMAGES FOR DELAYS
ALL TIME LIMITS STATED IN THE CONTRACT DOCUMENTS ARE OF THE ESSENCE OF
THE AGREEMENT. EXCEPT AS PROVIDED HEREIN, NO CLAIM FOR DAMAGES OR ANY
CLAIM OTHER THAN FOR AN EXTENSION OF TIME SHALL BE MADE OR ASSERTED
AGAINST CITY BY REASON OF ANY DELAYS. Contractor shall not be entitled to an increase
in the construction cost or payment or compensation of any kind from City for direct, indirect,
consequential, impact or other costs, expenses or damages including but not limited to costs of
acceleration or inefficiency, arising because of delay, disruption, interference or hindrance from
any cause whatsoever, whether such delay, disruption, interference be reasonable or
unreasonable, foreseeable or unforeseeable, or avoidable or unavoidable; provided, however,
that this provision shall not preclude recovery of damages by Contractor for hindrances or delays
due solely to fraud, bad faith or active interference on the part of City or its agents. In addition, if
Contractor is delayed at any time in the progress of the Work by an act or neglect of the City's
employees, or separate contractors employed by the City, or by changes ordered in the Work, or
by delay authorized by the City pending arbitration, then the Contract Time shall be reasonably
extended by Change Order. Furthermore, if Contractor is delayed at any time in the progress of
the Work by labor disputes, fire, unusual delay in deliveries, adverse weather conditions not
reasonably anticipated, unavoidable casualties or other causes beyond the Contractor's control,
or by other causes which the City and Contractor agree may justify delay, then the Contract Time
shall be reasonably extended by Change Order. Otherwise, Contractor shall be entitled only to
extensions of the Contract Time as the sole and exclusive remedy for such resulting delay, in
accordance with and to that extent specifically provided above. No extension of time shall be
granted for delays resulting from normal weather conditions prevailing in the area. An extension
of time will be considered for "Excusable Inclement Weather Delays" resulting in any weather
condition, the duration of which varies in excess of the average conditions expected, which is
unusual for the particular time and place where the Work is to be performed, or which could not
have been reasonably anticipated by the Contractor, as determined by the U.S. Weather Bureau
records for the preceding 3-year period. No extension of Contract Time will be allowed for any
inclement weather that could reasonably have been predicted as determined by the U.S. Weather
Bureau records. Should the contractor prepare to begin work at the regular starting time at the
beginning of any regular work shift on any day on which excusable inclement weather, or the
conditions resulting from the weather, or the condition of the Work prevents work from beginning
at the usual starting time, and the crew is dismissed as a result thereof, the Contractor will not be
charged for a working day, whether or not conditions change thereafter during said day, and the
major portion of the day could be considered to be suitable for such construction operations. The
Contractor shall base its construction schedule upon the inclusion of the number of days of
excusable inclement weather. No extension of the Contract Time due to excusable inclement
weather will be considered until after the said number of days of excusable inclement weather
has been reached. However, no reduction in Contract Time would be made if said number of days
of excusable inclement weather is not reached.
11. WAIVER OF LIENS
Prior to final payment of Contract Sum, a final waiver of lien shall be submitted to City by
Contractor from all suppliers, subcontractors, and/or Contractors who submitted a "Notice to
Owner" and a Consent of Surety on behalf of any and all other suppliers and subcontractors
who worked on the project that is the subject of this Agreement. Payment of the invoice and
acceptance of such payment by the Contractor shall release City form all claims of liability by
Contractor in connection with the agreement.
22-'1 T - Poi PaarA R000vabon Projrs.�
TA.MA�RAC
City of Tamarac The C' ity or you Purchasing and Contracts Division
12. WARRANTY
Contractor warrants the work against defect for a period of One 1 year from the date of City
approval of final payment. In the event that defect occurs during this time, Contractor shall
perform such steps as required to remedy the defects. Contractor shall be responsible for any
damages caused by defect to affected area or to interior structure. The one (1) year warranty
period does not begin until approval of final payment for the entire project, and the subsequent
release of any Performance or Payment Bonds, which may be required by the original bid
document.
13. INDEMNIFICATION
13.1 The Contractor shall indemnify and hold harmless the City, its elected and appointed
officials, employees, and agents from any and all claims, suits, actions, damages,
liability, and expenses (including attorneys' fees) in connection with loss of life, bodily
or personal injury, or property damage, including loss of use thereof, directly or
indirectly caused by, resulting from, arising out of or occurring in connection with the
operations of the Contractor or its officers, employees, agents, subcontractors, or
independent Contractors, excepting only such loss of life, bodily or personal injury, or
property damage solely attributable to the gross negligence or willful misconduct of the
City or its elected or appointed officials and employees. The above provisions shall
survive the termination of this Agreement and shall pertain to any occurrence during
the term of this Agreement, even though the claim may be made after the termination
hereof.
13.2 Nothing contained herein is intended nor shall be construed to waive City's rights and
immunities under the common law or Florida Statutes 768.28, as amended from time
to time
14. NON-DISCRIMINATION & EQUAL OPPORTUNITY EMPLOYMENT
14.1 During the performance of the Contract, the Contractor and its subcontractors shall
not discriminate against any employee or applicant for employment because of race,
color, sex including pregnancy, religion, age, national origin, marital status, political
affiliation, familial status, sexual orientation, gender identity and expression, genetic
information or disability if qualified.
14.2 The Contractor will take affirmative action to ensure that employees and those of its
subcontractors are treated during employment, without regard to their race, color, sex
including pregnancy, religion, age, national origin, marital status, political affiliation,
familial status, sexual orientation, gender identity or expression, or disability if qualified.
Such actions must include, but not be limited to, the following: employment, promotion;
demotion or transfer; recruitment or recruitment advertising, layoff or termination; rates
of pay or other forms of compensation; and selection for training, including
apprenticeship.
14.3 The Contractor and its subcontractors shall agree to post in conspicuous places,
available to its employees and applicants for employment, notices to be provided by
the contracting officer setting forth the provisions of this nondiscrimination clause. The
Contractor further agrees that he/she will ensure that all subcontractors, if any, will be
made aware of and will comply with this nondiscrimination clause.
15. INDEPENDENT CONTRACTOR
22-f 1B Dog Park R000vation P^i ,ri
TAMARAC
City of Tamarac Th�C y For �Your rLife Purchasing and Contracts Division
This Agreement does not create an employee/employer relationship between the Parties. It is
the intent of the Parties that the Contractor is an independent contractor under this Agreement
and not the City's employee for any purposes, including but not limited to, the application of
the Fair Labor Standards Act minimum wage and overtime payments, Federal Insurance
Contribution Act, the Social Security Act, the Federal Unemployment Tax Act, the provisions
of the Internal Revenue Code, the State Worker's Compensation Act, and the State
Unemployment Insurance law. The Contractor shall retain sole and absolute discretion in the
judgment of the manner and means of carrying out Contractor's activities and responsibilities
hereunder provided, further that administrative procedures applicable to services rendered
under this Agreement shall be those of Contractor, which policies of Contractor shall not conflict
with City, State, or United States policies, rules or regulations relating to the use of Contractor's
funds provided for herein. The Contractor agrees that it is a separate and independent
enterprise from the City, that it had full opportunity to find other business, that it has made its
own investment in its business, and that it will utilize a high level of skill necessary to perform
the work. This Agreement shall not be construed as creating any joint employment relationship
between the Contractor and the City and the City will not be liable for any obligation incurred
by Contractor, including but not limited to unpaid minimum wages and/or overtime premiums.
16. ASSIGNMENT AND SUBCONTRACTING
Contractor shall not transfer or assign the performance required by this Agreement without the
prior consent of the City. This Agreement, or any portion thereof, shall not be subcontracted
without the prior written consent of the city.
17. NOTICE
Whenever either party desires or is required under this Agreement to give notice to any other
party, it must be given by written notice either delivered in person, sent by U.S. Certified Mail,
U.S. Express Mail, air or ground courier services, or by messenger service, as follows:
CITY
City Manager
City of Tamarac
7525 N.W. 88th Avenue
Tamarac, FL 33321
With a copy to the City Attorney at the following address:
Fox Rothschild LLP
2 South Biscayne Boulevard
One Biscayne Tower, Suite 2750
Miami, FL 33131
Attn: John R. Herin, Jr.
CONTRACTOR
Name: Maceda Contractors, LLC.
Address:5030 SW 173rd Road, South West Ranches, Florida 33331
FIN/EIN:26-2158406
Contract Licensee:CGC-1514076
Contact: Fidel Maceda
Email: macedagc(a)gmail.com
Phone: 786-237-1726
Fax:
22-118 — Dori P;arh ,4enovtabon
TAMARAC
City of Tamarac The City For Your Life Purchasing and Contracts Division
_....... - - —...__ ......... _.... —...---.....
-----__ ._.._...--- .—_.
18. TERMINATION
18.1 Termination for Convenience: This Agreement may be terminated by City for
convenience, upon seven (7) days of written notice by terminating party to the other
party for such termination in which event Contractor shall be paid its compensation for
services performed to termination date, including services reasonably related to
termination. In the event that Contractor abandons this Agreement or causes it to be
terminated, Contractor shall indemnify city against loss pertaining to this termination.
18.2 Default by Contractor: In addition to all other remedies available to the City, this
Agreement shall be subject to cancellation by the City for cause, should the Contractor
neglect or fail to perform or observe any of the terms, provisions, conditions, or
requirements herein contained, if such neglect or failure shall continue for a period of
thirty (30) days after receipt by Contractor of written notice of such neglect or failure.
19. AGREEMENT SUBJECT TO FUNDING
This agreement shall remain in full force and effect only as long as the expenditures provided
for in the Agreement have been appropriated by the City Commission of the City of Tamarac
in the annual budget for each fiscal year of this Agreement and is subject to termination based
on lack of funding.
20. VENUE
This Agreement shall be governed by the laws of the State of Florida as now and hereafter in
force. The venue for actions arising out of this agreement is fixed in Broward County, Florida.
21. SIGNATORY AUTHORITY
The Contractor shall provide the City with copies of requisite documentation evidencing that
the signatory for Contractor has the authority to enter into this Agreement.
22. SEVERABILITY; WAIVER OF PROVISIONS
Any provision in this Agreement that is prohibited or unenforceable in any jurisdiction shall, as
to such jurisdiction, be ineffective to the extent of such prohibition or unenforceability without
invalidating the remaining provisions hereof or affecting validity or enforceability of such
provisions in any other jurisdiction. The non -enforcement of any provision by either party shall
not constitute a waiver of that provision nor shall it affect enforceability of that provision or of
the remainder of this Agreement.
23. UNCONTROLLABLE CIRCUMSTANCES
23.1 Neither the City nor Contractor shall be considered to be in default of this Agreement if
delays in or failure of performance shall be due to Uncontrollable Forces, the effect of
which, by the exercise of reasonable diligence, the non -performing party could not avoid.
The term "Uncontrollable Forces" shall mean any event which results in the prevention
or delay of performance by a party of its obligations under this Agreement and which is
beyond the reasonable control of the nonperforming party. It includes, but is not limited
to fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance,
sabotage, and governmental actions, such as delays in permitting due to outside
agencies, which are beyond the Contractor's control.
23.2 Neither party shall, however, be excused from performance if nonperformance is due to
forces, which are preventable, removable, or remediable, and which the nonperforming
party could have, with the exercise of reasonable diligence, prevented, removed, or
remedied with reasonable dispatch. The nonperforming party shall, within a reasonable
22-11 3 L.n7 Park Rercvaticn Pr;i;r:'r
TAMARAC
City of Tamarac The City For Your Life Purchasing and Contracts Division
- ............ ............. -- ...... .
time of being prevented or delayed from performance by an uncontrollable force, give
written notice to the other party describing the circumstances and uncontrollable forces
preventing continued performance of the obligations of this Agreement.
24. MERGER; AMENDMENT
This Agreement constitutes the entire Agreement between the Contractor and the City, and
negotiations and oral understandings between the parties are merged herein. This Agreement
can be supplemented and/or amended only by a written document executed by both the
Contractor and the City.
25. NO CONSTRUCTION AGAINST DRAFTING PARTY
Each party to this Agreement expressly recognizes that this Agreement results from the
negotiation process in which each party was represented by counsel and contributed to the
drafting of this Agreement. Given this fact, no legal or other presumptions against the party
drafting this Agreement concerning its construction, interpretation or otherwise accrue to the
benefit of any party to the Agreement, and each party expressly waives the right to assert such
a presumption in any proceedings or disputes connected with, arising out of, or involving this
Agreement.
26. CONTINGENT FEES
The Contractor warrants that it has not employed or retained any company or person, other
than a bona fide employee working solely for the Contractor to solicit or secure this Agreement
and that it has not paid or agreed to pay any person, company, corporation, individual or firm,
other than a bona fide employee working solely for the Contractor, any fee, commission,
percentage, gift or any other consideration contingent upon or resulting from the award or
making of this Agreement.
27. SCRUTINIZED COMPANIES - 287.135 AND 215.473
27.1 By execution of this Agreement, Contractor certifies that Contractor is not participating
in a boycott of Israel. Contractor further certifies that Contractor is not on the Scrutinized
Companies that Boycott Israel list, not on the Scrutinized Companies with Activities in
Sudan List, and not on the Scrutinized Companies with Activities in the Iran Petroleum
Energy Sector List, or has Contractor been engaged in business operations in Syria.
Subject to limited exceptions provided in state law, the City will not contract for the
provision of goods or services with any scrutinized company referred to above.
27.2 Submitting a false certification shall be deemed a material breach of contract. The City
shall provide notice, in writing, to Contractor of the City's determination concerning the
false certification. Contractor shall have five (5) days from receipt of notice to refute the
false certification allegation. If such false certification is discovered during the active
contract term, Contractor shall have ninety (90) days following receipt of the notice to
respond in writing and demonstrate that the determination of false certification was
made in error. If Contractor does not demonstrate that the City's determination of false
certification was made in error then the City shall have the right to terminate the contract
and seek civil remedies pursuant to Section 287.135, Florida Statutes, as amended
from time to time.
28. PUBLIC RECORDS
28.1 The CITY is a public agency subject to Chapter 119, Florida Statutes. The
CONTRACTOR shall comply with Florida's Public Records Law. Specifically,
CONTRACTOR shall:
22- NIB -- Dog Yc3rn Ronovabon P oju,-f
City 0) Tam: amc
TA�M�ARAC
The City For Yo i a Purchasing and Contracts Division
28.1.1 Keep and maintain public records required by the CITY in order to perform the
service.
28.1.2 Upon request from the CITY, provide the public agency with a copy of the
requested records or allow the records to be inspected or copied within a
reasonable time at no cost to the CITY.
28.1.3 Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law
for the duration of the contract term and following completion of the Agreement
and any renewals thereof if CONTRACTOR does not transfer the records to the
CITY.
28.1.4 Upon completion of the Agreement, transfer, at no cost to the CITY, all public
records in possession of CONTRACTOR, or keep and maintain public records
required by the CITY to perform the service. If CONTRACTOR transfers all public
records to the CITY upon completion of the Agreement, CONTRACTOR shall
destroy any duplicate public records that are exempt or confidential and exempt
from public records disclosure requirements. If CONTRACTOR keeps and
maintains public records upon completion of the Agreement, CONTRACTOR
shall meet all applicable requirements for retaining public records. All records
stored electronically must be provided to the CITY, upon request from the CITY's
custodian of public records in a format that is compatible with the information
technology systems of the CITY.
28.2 During the term of this Agreement and any renewals, CONTRACTOR shall maintain all
books, reports and records in accordance with generally accepted accounting practices
and standards for records directly related to this contract.
29. E-VERIFY
As a condition precedent to entering into this Agreement, and in compliance with Section 448.095,
Fla. Stat., Contractor and its subcontractors shall, register with and use the E-Verify system to
verify work authorization status of all employees hired after January 1, 2021. Contractor shall
require each of its subcontractors to provide Contractor with an affidavit stating that the
subcontractor does not employ, contract with, or subcontract with an unauthorized alien.
Contractor shall maintain a copy of the subcontractor's affidavit as part of and pursuant to the
records retention requirements of this Agreement. City, Contractor, or any
subcontractor/subconsultant who has a good faith belief that a person or entity with which it is
contracting has knowingly violated Section 448.09(1), Fla. Stat. or the provisions of this section
shall terminate the contract with the person or entity. City, upon good faith belief that a
subcontractor knowingly violated the provisions of this section; but Contractor otherwise complied,
shall promptly notify Contractor and Contractor shall immediately terminate the contract with the
subcontractor. An agreement or contract terminated under the provisions of this section is not a
breach of contract and may not be considered such. Any agreement or contract termination under
the provisions of this section may be challenged pursuant to Section 448.095(2)(d), Fla. Stat.
Contractor acknowledges that upon termination of this Agreement by the City for a violation of this
section by Contractor, Contractor may not be awarded a public contract for at least one (1) year.
Contractor further acknowledges that Contractor is liable for any additional costs incurred by the
City as a result of termination of any contract for a violation of this section. Contractor or
subcontractor shall insert in any subcontracts the clauses set forth in this section; requiring the
subcontractors to include these clauses in any lower tier subcontracts. Contractor shall be
The City For Your Life :'urchasing and Contracts Diva
responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set
forth in this section.
30. CUSTODIAN OF RECORDS
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE
APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE
CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING
TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC
RECORDS AT:
CITY CLERK
7525 NW 88TH AVENUE
ROOM 101
TAMARAC, FL 33321
(954) 597-3505
CITYCLERK@TAMARAC.ORG
22-118 — Dog Park Renovation Project 11
City of Tamarac The City For Your Life Purchasing and Contracts Division
_.. .......... .............. ....
IN WITNESS WHEREOF, the parties have made and executed this Agreement on the
respective dates under each signature. CITY OF TAMARAC, signing by and through its
Mayor and City Manager, and CONTRACTOR, signing by and through its Member Manager
duly authorized to execute same.
G•
ESTABLISHED Q
i 7� : 1963
0'.. • SEAL .• O
. ,<
ATTEST:
Kimberly Di!l on, Acting City Clerk
CITY OF TAMARAC
k1l e4 � 16
Mic elle J. Gomez, Maebor
7hl6en Gunn, City MaMger
Date
o'�J lS-1,022 A
Date
ATTEST:
Signature of Corporate Secretary
4p/l koLf ODI v
Corporate Secy. (Printed Name)
(CORPORATE SEAL)
as to form and�legal sufficiency:
ohn ' , Jr., City,At rney
-7 1 122_
CONTRACTOR
Maceda Contractors,JLLC.
Company Na,1---'
Signature'6VN4,4rffiber Manager
Fidel Maceda
MGRM — Member - Manager
Date
G-2Z-2o12
TAMARAC
City of Tamarac The City For Your Life purchasing and Contracts Division
-
CORPORATE ACKNOWLEDGEMENT
STATE OF
:SS
COUNTY OF :
I HEREBY CERTIFY that on this day, before me, an Officer duly authorized in the State aforesaid and
in the County aforesaid to take acknowledgments, personally appeared Fidel Maceda, Member
Manager of Maceda Contractors, LLC., a Florida Corporation, to me known to be the person(s)
described in and who executed the foregoing instrument and acknowledged before me that he/she
executed the same.
WITNESS my hand and official seal this day of ,tj X,e ZZ, 20ZZ
1,JRAK.UGUE?0
•:,>'F <';:,
= r°' �, Commission # GG 331180
Septymber 5, 2023
`•:cp
*'r,od„k°;'
f xpires
r•+no uQ0 3u5-j0?9
T^�rT.qy Fa;pAIII
?ur�le9 u
, 91� UvAlo
Sig ature of Nota ublic
State of Florida at Large
(.."vim uv
Print, Type or Stamp
Name of Notary Public
Personally, known to me or
❑ Produced Identification
Type of I.D. Produced
-❑-- DID take an oath, or
❑ DID NOT take an oath.
22-116 - Dog Park Renovation, Project