HomeMy WebLinkAboutCity of Tamarac Resolution R-2023-012Temp. Reso. #13807
January 25, 2023
Page 1 of 5
CITY OF TAMARAC, FLORIDA
RESOLUTION NO. R-2023 - 019--
A RESOLUTION OF THE CITY COMMISSION OF
THE CITY OF TAMARAC, FLORIDA, AWARDING
ITB #22-20B, TAMARAC COMMUNITY CENTER
RESTROOMS RENOVATION PROJECT TO KHAN
BUILDERS, INC. AND AUTHORIZING THE
EXECUTION OF AN AGREEMENT BETWEEN
THE CITY OF TAMARAC AND KHAN BUILDERS,
INC. AT A CONTRACT COST NOT TO EXCEED
$183,220.63 AND A CONTINGENCY ALLOWANCE
OF $18,322.06 FOR A TOTAL PROJECT BUDGET
OF $201,542.69; AUTHORIZING AN
APPROPRIATION AND EXPENDITURE OF
FUNDS IN THE AMOUNT NOT TO EXCEED
$201,542.69 TO BE INCLUDED IN A FUTURE
BUDGET AMENDMENT; AUTHORIZING AN
EXPENDITURE FROM THE APPROPRIATE
ACCOUNT; PROVIDING FOR CONFLICTS;
PROVIDING FOR SEVERABILITY; AND
PROVIDING AN EFFECTIVE DATE.
WHEREAS, Florida Statutes provide that municipalities shall have the
governmental, corporate, and proprietary powers to enable them to conduct
municipal government, perform municipal functions and render municipal service,
and exercise any power for municipal purposes, except when expressly prohibited
by law ; and
WHEREAS, Article IV, Section 4.07 of the City Charter of the City of
Tamarac ("City) empowers the City to adopt, amend or repeal such ordinances
and resolutions as may be required for the proper governing of the City; and
WHEREAS, the City desires to provide residents with a higher quality of
service by improving its indoor recreation facilities; and
Temp. Reso. #13807
January 25, 2023
Page 2 of 5
WHEREAS, the Tamarac Community Center is located at 8601 West
Commercial Boulevard in the City of Tamarac, Florida; and
WHEREAS, The City of Tamarac publicly advertised ITB #22-20B for the
Tamarac Community Center Restrooms Renovation Project on June 17, 2022;
and
WHEREAS, Bid Proposals ITB #22-20B is incorporated by reference and
available in the Office of the City Clerk; and
WHEREAS the City received seven (7) responses from firms including
KHAN BUILDERS, INC.; and
and
WHEREAS, a copy of the ranking sheet is attached hereto as "Exhibit 1";
WHEREAS, The Purchasing Division determined that the proposal
response submitted by KHAN BUILDERS, INC., incorporated by reference and
available in the Office of the City Clerk, was the most responsive and responsible
bid, and best able to meet the needs of the City; and
WHEREAS, the City of Tamarac has prepared an agreement (attached
hereto as "Exhibit 2") with KHAN BUILDERS, INC., for their services based on their
proposal at a cost not to exceed $183,220.63; and
WHEREAS, a contingency allowance in the amount of $18,322.06 is
added to this project to be used only on an as -needed basis. The City Manager,
or his designee, shall be authorized to make changes, issue Change Orders
pursuant to Section 6-1470) of the City Code, and close the contract award
Temp. Reso. #13807
January 25, 2023
Page 3 of 5
including, but not limited to, making final payment and release of bonds when the
work has been successfully completed within the terms and conditions of the
contract and within the price; and
WHEREAS, it is the recommendation of the Director of Public Services,
Director of Parks and Recreation and the Purchasing and Contracts Manager that
the contract for the Tamarac Community Center Restrooms Renovation Project be
awarded to KHAN BUILDERS, INC.; and
WHEREAS, the City Commission of the City of Tamarac, deems it to be in
the best interests of the citizens and residents of the City of Tamarac to award the
contract for the Tamarac Community Center Restrooms Renovations Project to
Khan Builders, Inc. at a cost not to exceed $183,220.63 and a contigency in the
amount of 18,322.06, for a total budget of $201,542.69.
NOW, THEREFORE, BE IT RESOLVED BY THE CITY COMMISSION OF
THE CITY OF TAMARAC, FLORIDA THAT:
SECTION 1: The foregoing recitals are true and correct and hereby
adopted as the legislative and administrative findings of the City Commission; all
exhibits attached hereto are incorporated herein and made a specific part of this
Resolution.
SECTION 2: The City Commission hereby awards ITB #22-20B to and
approves an Agreement between the City of Tamarac and KHAN BUILDERS, INC.
for the Tamarac Community Center Restrooms Renovation Project and the
appropriate City Officials are hereby authorized to execute the Agreement to
provide for the Tamarac Community Center Restrooms Renovation Project.
Temp. Reso. #13807
January 25, 2023
Page 4 of 5
SECTION 3: The appropriate City Officials are authorized to execute the
Agreement, expend budgeted funds, make changes to the scope of the Project,
issue Change Orders, and close the contract award including, but not limited to,
making final payment and release of bonds when the work has been successfully
completed with the terms and conditions of the Agreement pursuant to Section 6-
1470) of the City Code.
SECTION 4: An expenditure for a contract cost of $183,220.63 and a
contingency in the amount of $18,322.06, for a total project budget of $201,542.69
for said purpose is hereby approved.
SECTION 5: Funding for the Tamarac Community Center Restrooms
Renovation Project shall be available through an appropriation and expenditure of
funds in the amount not to exceed $201,542.69, which will be included in a future
Budget Amendment by November 30, 2023, pursuant to F.S. 166.241(2).
SECTION 6: All resolutions or part of resolutions in conflict herewith are
hereby repealed to the extent of such conflict.
SECTION 7: If any clause, section, other part, or application of this
Resolution is held by any court of competent jurisdiction to be unconstitutional or
invalid, in part or application it shall not affect the validity of the remaining portions
or applications of this Resolution.
SECTION 8: This Resolution shall become effective immediately upon
adoption.
Temp. Reso. #13807
January 25, 2023
Page 5 of 5
PASSED, ADOPTED AND APPROVED this ZK_ day of
2023.
ICHELLE J. 1:;OfAEZ
MAYOR
ATTEST:
1-
KIMBLIRLY DILLON, CMC
CITY CLERK
RECORD OF COMMISSION VOTE
MAYOR GOMEZ
DIST 1:
V/M BOLTON
DIST 2:
COMM.WRIGHTJR.
DIST 3:
COMM. VILLALOBOS
DIST 4:
COMM. DANIEL N r
APPROVED AS TO FORM AND LEGAL SUFFICIENCY FOR THE USE AND
RELIANCE OF THE CITY OF TAMARAC ONLY.
li-KNS OTIDINOT
CITY ATTORNEY
o
(_
/o
0
at
-
!�`
\
}
\
\
\
\
\
(
\
\
()
}
\{}
(
/
7
)
][;#
!
2
§
°°
G
_
■
�
-
o
;;Bk
s
,
,
�
#
#
„
«.
�
a
■�s
■
3
M
\
,
!
\
|
(
�
wl
()m
§k§
|
\k)■
(
2
2
]
;■;2
0\
\ \
\
\ \
\
\ \
\
\
\
\
\
a§=
§:
�
-
'8'8
m
'
\
f/\ff
f
; ;
k
s
s
;
k)
s
■
■
;
;
m
■
;s
#;
; ;
■ ,;,
a
)i
_
_ 1
a
3
$
$
$
g
$
$
$ $
Sb
$
$
$
$
$ $
$
$
o
r
g
N
a
![$$
I([
�(|§
(
-
(f4�,-,,
!
-
- --
--
()
{{\�{�)k
�)\ƒ`k
}\
\
(
4;---;-
\\/
\\/\
z
}
}
}
t
!
2
k
e
4
k
o■
k
e■
4
k
4#||
/k
k
§
}
(
k
k)
k
)
k
§
k
§
k
�
k
ƒ%
\\
\
k
(
, ■
k
;
■
;
E
[
|
(
k
■
k■
;
\
;
«2
°
,,
_
3`3
|;!!!!/
\/
i
\
|!)
{
/
�|2a
(
t
� §
|
�
■ ■
;
�
`
§a�
§
)
]
!
a
,
■
(
(
�
#
�
�
w
■
■
|
|
i
k
k
k
;
k
e
e
a
\
/4■■
;
)
|
;
§
,
k
■
■;§;
4
; ;
[
; �
[ ]
2
2
IN
TAt ACr
The City For Your Life
City of Tamarac Purchasing and Contracts Division
CONSTRUCTION AGREEMENT
BETWEEN THE CITY OF TAMARAC
AND
KHAN BUILDERS, INC.
THIS AGREEMENT is made and entered into this:;0—day of �-tr a fj , 20`�5 by and
between the City of Tamarac, a municipal corporation with principal offices located at 7525 N.W. 88th
Ave., Tamarac, FL 33321 (the "CITY") and Khan Builders, Inc., a corporation with principal offices
located at 11240 SW 20th Street, Miramar, Florida 33025 (the "Contractor") to provide for construction
services for the Tamarac Community Center Restrooms Renovation.
Now therefore, in consideration of the mutual covenants hereinafter set forth, the City and Contractor
agree as follows:
1. THE CONTRACT DOCUMENTS
The Contract Documents consist of this Agreement, Bid Document No. 22-20B for "Tamarac
Community Center Restrooms Renovation", issued by the City of Tamarac on June 17, 2022
including all conditions therein, (General Terms and Conditions, Special Conditions and/or
Special Provisions, Instructions to Bidder's), drawings and/or schematic plans, Technical
Specifications, all addenda, the Contractor's Bid response dated July 25, 2022, and all
modifications issued after execution of this Agreement. These contract documents form the
Agreement, and all are as fully a part of the Agreement as if attached to this Agreement or
repeated therein. In the event that there is a conflict between Bid 22-20B for "Tamarac
Community Center Restrooms Renovation" as issued by City, and the contractor's bid
response; Bid 22-20B for "Tamarac Community Center Restroom Renovation" as issued by
City shall take precedence over the contractor's bid response. Furthermore, in the event of a
conflict between this document and any other Contract Documents, this Agreement shall
prevail.
2. THE WORK
2.1. The Contractor shall perform all work for the City required by the contract documents
as set forth below:
2.1.1 Contractor shall furnish all labor, materials, and equipment necessary to
complete the scope of work, as outlined in the contract documents including all
Addendums, Exhibits, Attachments and Appendices.
2.1.2 Contractor shall supervise the work force to ensure that all workers conduct
themselves and perform their work in a safe and professional manner.
Contractor shall comply with all OSHA safety rules and regulations in the
operation of equipment and in the performance of the work. Contractor shall at
all times have a competent, English speaking field supervisor on the job site to
enforce these policies and procedures at the Contractor's expense.
2.1.3 Contractor shall provide the City with seventy-two (72) hours written notice prior
to the beginning of work under this Agreement and prior to any schedule change
with the exception of changes caused by inclement weather.
2.1.4 Contractor shall comply with any and all Federal, State, and local laws and
regulations now in effect, or hereinafter enacted during the term of this
22-20B Tamarac Community Center Restrooms Renovation
TA�ARAC
The City For Your Life
City of Tamarac Purchasing and Contracts Division
Agreement, which are applicable to the Contractor, its employees, agents or
subcontractors, if any, with respect to the work and services described herein.
3. INSURANCE
3.1. Contractor shall obtain at Contractor's expense all necessary insurance in such form
and amount as specified in the original bid document or as required by the City's Risk
and Safety Manager before beginning work under this Agreement including, but not
limited to, Workers' Compensation, Commercial General Liability, Builder's Risk and all
other insurance as required by the City, including Professional Liability when
appropriate. Contractor shall maintain such insurance in full force and effect during the
life of this Agreement. Contractor shall provide to the City's Risk and Safety Manager
certificates of all insurances required under this section prior to beginning any work
under this Agreement. The Contractor will ensure that all subcontractors comply with
the above guidelines and will retain all necessary insurance in force throughout the
term of this agreement.
3.2. Contractor shall indemnify and hold the City harmless for any damages resulting from
failure of the Contractor to take out and maintain such insurance. Contractor's Liability
Insurance policies shall be endorsed to add the City as an additional insured.
Contractor shall be responsible for payment of all deductibles and self-insurance
retentions on Contractor's Liability Insurance policies. The following are required types
and minimum limits of insurance coverage, which the Bidder agrees to maintain during
the term of this contract:
• General Liability - $1 M/$2M
• Automobile — $1 M/$1 M
• Workers Comp — Statutory
4. PERFORMANCE, PAYMENT AND WARRANTY BONDS
4.1 Within fifteen (15) calendar days after contract award, but in any event prior to
commencing work, the Successful Bidder shall execute and furnish the CITY a
Performance Bond and Payment Bond, each written by a corporate surety, having a
resident agent in the State of Florida and having been in business with a record of
successful continuous operation for at least five (5) years. The surety shall hold a
current certificate of authority from the Secretary of Treasury of the United States as an
acceptable surety on federal bonds in accordance with United States Department of
Treasury Circular No. 570.
4.2 The Contractor shall be required to provide acceptable, separate Performance and
Payment Bonds in the amount of one hundred 100% of the bid award amount as
security for the faithful project performance and payment of all the Contractor's
obligations under the contract documents, per City Code Section 10-156. The
Performance Bond shall be conditioned that the Successful Bidder performs the
contract in the time and manner prescribed in the contract. The Payment Bond shall be
conditioned that the Successful Bidder promptly make payments to all persons who
supply the Successful Bidder in the prosecution of the work provided for in the contract
and shall provide that the surety shall pay the same in the amount not exceeding the
sum provided in such bonds, together with interest at the maximum rate allowed by law
and that they shall indemnify and hold harmless the CITY to the extent of any and all
payments in connection with the carrying out of said contract which the CITY may be
required to make under the law. Payment and Performance Bonds must be submitted
on City forms, included herein. At the completion and formal approval and acceptance
of all work associated with the project, a one-year warranty period will begin. If the
22-20B Tamarac Community Center Restrooms Renovation
The City For Your Life
City Tamarac Purchasing and Contracts Division
surety on any bond furnished by the Contractor is declared bankrupt or becomes
insolvent, or its right to do business is terminated in Florida, the Contractor shall, within
seven (7) days thereafter, substitute another bond meeting the requirements outlined
above, which must also be acceptable to the City.
4.3 Such bonds shall continue in effect for one (1) year after final payment becomes due
and approved except as otherwise provided by law or regulation or by the Contract
Documents with the final sum of the Warranty bonds equal to twenty five percent (25%)
of the total value of the Contract price (including executed change orders), conditioned
that the Contractor correct any defective or faulty work or material which appear within
one (1) year after final completion of the Contract, upon notification by CITY. The
Warranty Bond shall cover all the cost of labor as well as materials
4.4 Pursuant to the requirements of Chapter 255.05 (1) (b), Florida Statutes, the Contractor
shall ensure that the Performance and Payment Bond or Bonds referenced above
shall be recorded in the Public records of Broward County at the Bidder's
expense. Proof of recording must be submitted to the City prior to issuance of
any purchase order or payment by the City. One (1) set of original Performance
and Payment Bond documents is required to be provided to the City prior to the
issuance of any Notice to Proceed by the City
5. TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION
5.1 The work to be performed under this Agreement shall be commenced after City
execution of the Agreement and not later than ten (10) days after the date that
Contractor receives the City's Notice to Proceed. The work shall be completed within
One Hundred Eighty (180) Calendar days for Final Completion from issuance of City's
Notice to Proceed, subject to any permitted extensions of time under the Contract
Documents. The work under this agreement shall be substantially complete (i.e.
Substantial Completion) within One Hundred Fifty (150) calendar days from issuance
of City's Notice to Proceed.
5.2 During the pre -construction portion of the work hereunder, the parties agree to work
diligently and in good faith in performing their obligations hereunder, so that all required
permits for the construction portion of the work may be obtained by the City in
accordance with the approved Schedule included in the Contract Documents. In the
event that any delays in the pre -construction or construction portion of the work occur,
despite the diligent efforts of the parties hereto, and such delays are the result of force
majeure or are otherwise outside of the control of either party hereto, then the parties
shall agree on an equitable extension of the time for substantial completion hereunder
in accordance with the requirements of the Contract Documents.
6. CONTRACT SUM
The Contract Sum for the above work is a "not to exceed" total of One Hundred Eighty -Three
Thousand Two Hundred Twenty Dollars and Sixty -Three Cents ($183,220.63).
7. PAYMENTS
Payment, upon City approval, will be made monthly for work that has been completed,
inspected and properly invoiced (Application for Payment). A retainage of five percent (5%) will
be deducted from each monthly payment through project completion, upon City review and
approval. Retainage monies will be released upon satisfactory completion and final inspection
of the specific work order. Invoices must bear the bid number, project name, project number,
and purchase order number. The City has up to twenty-five (25) business days to review,
approve and pay all invoices after receipt of an approved application for payment. The
Contractor shall invoice the City and provide a written request to the City to commence the
22-208 Tamarac Community Center Restrooms Renovation
TAMARAC
The City For Your Life
City of Tamarac Purchasing and Contracts Division
one-year warranty period. All necessary Release of Liens and Affidavits shall be processed
before the warranty period begins, following the completion of all work, certificates of
approvals, punch lists, etc., in accordance with the Contract Documents. All payments shall be
governed by the Florida Prompt Payment Act, F.S., Part VII, Chapter 218.
8. REMEDIES
8.1 Damages: The City reserves the right to recover any ascertainable actual damages
incurred including right to withhold payment as a result of the failure of the Contractor
to perform in accordance with the requirements of this Agreement, or for losses
sustained by the City resultant from the Contractor's failure to perform in accordance
with the requirements of this Agreement, including City's right to withhold payment.
8.2 Correction of Work: If, in the judgment of the City, work provided by the Contractor does
not conform to the requirements of this Agreement, or if the work exhibits poor
workmanship, the City reserves the right to require that the Contractor correct all
deficiencies in the work to bring the work into conformance without additional cost to
the City, and / or replace any personnel who fail to perform in accordance with the
requirements of this Agreement. Correction of all deficiencies shall not relieve the
Contractor of its duties and obligations under this Agreement in meeting all project
requirements and objectives including but not limited to achieving project milestones
(Substantial and Final Completion) in accordance with the Contract Documents. The
City shall be the sole judge of non-conformance, the quality of workmanship and any
impact it may have on the Project Schedule.
9. CHANGE ORDERS
9.1 All Change Orders shall include a maximum Overhead and Profit, not to exceed five
percent (5%) and five percent (5%) respectively (not cumulative).
9.2 Without invalidating the contract, without any monetary compensation, and without
notice to any surety, the City reserves and shall have the right to make increases,
decreases or other changes to the work as may be considered necessary or desirable
to complete the proposed construction in a satisfactory manner. The Contractor shall
not start work pursuant to a change order until the change order setting forth the
adjustments is approved by the City and executed by the City and Contractor. Once
the change order is so approved, the Contractor shall promptly proceed with the work.
9.3 The Contract Price constitutes the total compensation (subject to authorized
adjustments, if applicable) payable to the Contractor for performing the work. All duties,
responsibilities and obligations assigned to or undertaken by the Contractor shall be at
Contractor's expense without change in the Contract Price or Time except as approved
in writing by the City.
9.4 The Contract Price and/or Time may only be changed by a Change Order. A fully
executed change order for any extra work must exist before such extra work is begun.
Any claim for an increase or decrease in the Contract Price shall be based on written
notice delivered by the party making the claim to the other party promptly (but in no
event later than 15 calendar days) after the occurrence of the event giving rise to the
claim and stating the general nature of the claim. The amount of the claim with
supporting data shall be delivered (unless the City allows an additional period of time
to ascertain more accurate data in support of the claim) and shall be accompanied by
claimant's written statement that the amount claimed covers all known amounts to
which the claimant is entitled as a result of the occurrence of said event. No claim for
an adjustment in the Contract Price will be valid if not submitted in accordance with this
Paragraph.
4
22-208 Tamarac Community Center Restrooms Renovation
TAMARAC
,res1—�.•�
ON of Tamarac
The City For Your Life
Purchasmp and Contracts Division
9.5 The Contract Time may only be changed by a Change Order. A fully executed change
order must exist prior to extension of the contract time.
9.6 Any claim for an extension of the Contract Time shall be based on written notice
delivered by the party making the claim to the other party no later than fifteen (15)
calendar days after the occurrence of the event giving rise to the claim. Notice of the
extent of the claim shall be delivered with supporting data and stating the general nature
of the claim. Contractor hereby agrees to waive rights to recover any lost time or
incurred costs from delays unless Contractor has given the notice and the supporting
data required by this Paragraph.
9.7 Extensions of time shall be considered and will be based solely upon the effect of delays
to the work as a whole. Extensions of time shall not be granted for delays to the work,
unless the Contractor can clearly demonstrate that such delays did or will, in fact, delay
the progress of work as a whole. Time extensions shall not be allowed for delays to
parts of the work that are not on the critical path of the project schedule. Time
extensions shall not be granted until all float or contingency time, at the time of delay,
available to absorb specific delays and associated impacts is used. Extensions of time
for delays due to Contractor's inability to perform work in a timely manner, failure to
properly coordinate work that causes adverse impact on project schedule or negligence
to properly sequence the work in a manner to meet all project obligations in accordance
with the Contract Documents shall not be accepted.
9.8 In the event satisfactory adjustment cannot be reached by City and Contractor for any
item requiring a change in the contract, and a change order has not been issued, City
reserves the right at its sole option to terminate the contract as it applies to these items
in question and make such arrangements as City deems necessary to complete the
work. The cost borne by the City to complete the work shall be levied against the
Contractor including applicable mark up of ten percent (10%) for overhead and
engineering costs. The cost of any work covered by a change order for an increase or
decrease in contract price shall be determined by mutual acceptance of a Guaranteed
Maximum Price by the City and Contractor. If notice of any change in the contract or
contract time is required to be given to a surety by the provisions of the bond, the giving
of such notice shall be the Contractor's responsibility, and the amount of each
applicable bond shall be adjusted accordingly. The Contractor shall furnish proof of
such adjustment to the City. Failure of the Contractor to obtain such approval from the
Surety may be a basis for termination of this Contract by the City.
10. LIQUIDATED DAMAGES
Because of the importance of this project being finished on time, upon failure of the Contractor
to complete each individual requirement within the specified and mutually agreed upon time
frame (plus approved extensions, if any) the Contractor shall pay to the City the sum of Two
Hundred Fifty Dollars ($250.00) for each calendar day after the time specified for substantial
completion and the project is sufficiently complete for its intended use in accordance with the
Contract Documents, void of any safety concerns. In the event of a delay in completion beyond
the time frame set forth in the Contract Documents for Final Completion, after substantial
completion has been obtained, liquidated damages will be assessed against the Contractor in
the amount of One Hundred Twenty -Five Dollars and Zero Cents ($125.00) for each
calendar day beyond the time frame set in the Contract Documents until such work is
completed and readiness for final payment. This amount is not a penalty but liquated damages
to the City. Liquidated damages are hereby fixed and agreed upon between the parties,
recognizing the impossibility of precisely ascertaining the amount of damages that will be
sustained by the City because of such delay, and both parties desiring to obviate any question
of dispute concerning the amount of said damages and the cost and effect of the failure of the
5
22-20B Tamarac Community Center Restrooms Renovation
City of Tamarac The City For Your Life
Purchasmg and Contracts DIVISIon
Contractor to complete the Contract on time. City shall have the right to deduct from and retain
out moneys which may be due, or which may become due and payable to Contractor. The
amount of such liquidated damages and if the amount retained by City is insufficient to pay in
full such liquidated damages, Contractor shall pay in full such liquidated damages. Contractor
shall also be responsible for reimbursing City the total of all monies paid by the City to the
engineer for additional engineering, inspection and administrative services until the work is
complete.
11. NO DAMAGES FOR DELAYS
ALL TIME LIMITS STATED IN THE CONTRACT DOCUMENTS ARE OF THE
ESSENCE OF THE AGREEMENT. EXCEPT AS PROVIDED HEREIN, NO CLAIM FOR
DAMAGES OR ANY CLAIM OTHER THAN FOR AN EXTENSION OF TIME SHALL
BE MADE OR ASSERTED AGAINST CITY BY REASON OF ANY DELAYS. Contractor
shall not be entitled to an increase in the construction cost or payment or compensation
of any kind from City for direct, indirect, consequential, impact or other costs, expenses
or damages including but not limited to costs of acceleration or inefficiency, arising
because of delay, disruption, interference or hindrance from any cause whatsoever,
whether such delay, disruption, interference be reasonable or unreasonable, foreseeable
or unforeseeable, or avoidable or unavoidable; provided, however, that this provision
shall not preclude recovery of damages by Contractor for hindrances or delays due solely
to fraud, bad faith or active interference on the part of City or its agents. In addition, if
Contractor is delayed at any time in the progress of the Work by an act or neglect of the
City's employees, or separate contractors employed by the City, or by changes ordered
in the Work, or by delay authorized by the City pending arbitration, then the Contract Time
shall be reasonably extended by Change Order. Furthermore, if Contractor is delayed at
any time in the progress of the Work by labor disputes, fire, unusual delay in deliveries,
adverse weather conditions not reasonably anticipated, unavoidable casualties or other
causes beyond the Contractor's control, or by other causes which the City and Contractor
agree may justify delay, then the Contract Time shall be reasonably extended by Change
Order. Otherwise, Contractor shall be entitled only to extensions of the Contract Time as
the sole and exclusive remedy for such resulting delay, in accordance with and to that
extent specifically provided above. No extension of time shall be granted for delays
resulting from normal weather conditions prevailing in the area. An extension of time will
be considered for "Excusable Inclement Weather Delays" resulting in any weather
condition, the duration of which varies in excess of the average conditions expected,
which is unusual for the particular time and place where the Work is to be performed, or
which could not have been reasonably anticipated by the Contractor, as determined by
the U.S. Weather Bureau records for the preceding 3-year period. No extension of
Contract Time will be allowed for any inclement weather that could be reasonably have
been predicted from such weather records. Should the contractor prepare to begin work
at the regular starting time at the beginning of any regular work shift on any day on which
excusable inclement weather, or the conditions resulting from the weather, or the
condition of the Work prevents work from beginning at the usual starting time, and the
crew is dismissed as a result thereof, the Contractor will not be charged for a working
day, whether or not conditions change thereafter during said day, and the major portion
of the day could be considered to be suitable for such construction operations. The
Contractor shall base its construction schedule upon the inclusion of the number of days
6
22-208 Tamarac Community Center Restrooms Renovation
TAMARAC
The City For Your Life
City of Tamarac Purchasing and Contracts �IVI510n
of excusable inclement weather. No extension of the Contract Time due to excusable
inclement weather will be considered until after the said number of days of excusable
inclement weather has been reached. However, no reduction in Contract Time would be
made if said number of days of excusable inclement weather is not reached.
12. WAIVER OF LIENS
Prior to final payment of Contract Sum, a final waiver of lien shall be submitted to City by
Contractor from all suppliers, subcontractors, and/or Contractors who submitted a "Notice to
Owner" and a Consent of Surety on behalf of any and all other suppliers and subcontractors
who worked on the project that is the subject of this Agreement. Payment of the invoice and
acceptance of such payment by the Contractor shall release City form all claims of liability by
Contractor in connection with the agreement.
13. WARRANTY
Contractor warrants the work against defect for a period of One ( 1 ) years from the date
of City's Final Acceptance of the project and approval of final payment. In the event that defect
occurs during this time, Contractor shall perform such steps as required to remedy the defects.
Contractor shall be responsible for any damages caused by defect to affected area or to interior
structure. The one (1) year warranty period does not begin until approval of final payment for
the entire project, and the subsequent release of any Performance or Payment Bonds, which
may be required by the original bid document.
14. INDEMNIFICATION
14.1 The Contractor shall indemnify and hold harmless the City, its elected and appointed
officials, employees, and agents from any and all claims, suits, actions, damages,
liability, and expenses (including attorneys' fees) in connection with loss of life, bodily
or personal injury, or property damage, including loss of use thereof, directly or
indirectly caused by, resulting from, arising out of or occurring in connection with the
operations of the Contractor or its officers, employees, agents, subcontractors, or
independent Contractors, excepting only such loss of life, bodily or personal injury, or
property damage solely attributable to the gross negligence or willful misconduct of the
City or its elected or appointed officials and employees. The above provisions shall
survive the termination of this Agreement and shall pertain to any occurrence during
the term of this Agreement, even though the claim may be made after the termination
hereof.
14.2 Nothing contained herein is intended nor shall be construed to waive City's rights and
immunities under the common law or Florida Statutes 768.28, as amended from time
to time
15. NON-DISCRIMINATION & EQUAL OPPORTUNITY EMPLOYMENT
15.1 During the performance of the Contract, the Contractor and its subcontractors shall not
discriminate against any employee or applicant for employment because of race, color,
sex including pregnancy, religion, age, national origin, marital status, political affiliation,
familial status, sexual orientation, gender identity and expression, genetic information
or disability if qualified.
15.2 The Contractor will take affirmative action to ensure that employees and those of its
subcontractors are treated during employment, without regard to their race, color, sex
including pregnancy, religion, age, national origin, marital status, political affiliation,
familial status, sexual orientation, gender identity or expression, or disability if qualified.
7
22-20B Tamarac Community Center Restrooms Renovation
Temp. Reso# 13807
Exhibit 2
TAMARAC
The CHy For Your Life
City of Tamarac Purchasing and Contracts Division
Such actions must include, but not be limited to, the following: employment, promotion;
demotion or transfer; recruitment or recruitment advertisin g, layoff or termination; rates
of pay or other forms of compensation; and selection for trainina. includina
apprenticeship.
15.3 The Contractor and its subcontractors shall agree to post in conspicuous places,
available to its employees and applicants for employment, notices to be provided by
the contracting officer setting forth the provisions of this nondiscrimination clause. The
Contractor further agrees that he/she will ensure that all subcontractors, if any, will be
made aware of and will comply with this nondiscrimination clause.
16. INDEPENDENT CONTRACTOR
This Agreement does not create an employee/employer relationship between the Parties. It is
the intent of the Parties that the Contractor is an independent contractor under this Agreement
and not the City's employee for any purposes, including but not limited to, the application of
the Fair Labor Standards Act minimum wage and overtime payments, Federal Insurance
Contribution Act, the Social Security Act, the Federal Unemployment Tax Act, the provisions
of the Internal Revenue Code, the State Worker's Compensation Act, and the State
Unemployment Insurance law. The Contractor shall retain sole and absolute discretion in the
judgment of the manner and means of carrying out Contractor's activities and responsibilities
hereunder provided, further that administrative procedures applicable to services rendered
under this Agreement shall be those of Contractor, which policies of Contractor shall not conflict
with City, State, or United States policies, rules or regulations relating to the use of Contractor's
funds provided for herein. The Contractor agrees that it is a separate and independent
enterprise from the City, that it had full opportunity to find other business, that it has made its
own investment in its business, and that it will utilize a high level of skill necessary to perform
the work. This Agreement shall not be construed as creating any joint employment relationship
between the Contractor and the City and the City will not be liable for any obligation incurred
by Contractor, including but not limited to unpaid minimum wages and/or overtime premiums.
17. ASSIGNMENT AND SUBCONTRACTING
Contractor shall not transfer or assign the performance required by this Agreement without the
prior consent of the City. This Agreement, or any portion thereof, shall not be subcontracted
without the prior written consent of the city.
18. NOTICE
Whenever either party desires or is required under this Agreement to give notice to any other
party, it must be given by written notice either delivered in person, sent by U.S. Certified Mail,
U.S. Express Mail, air or ground courier services, or by messenger service, as follows:
CITY
City Manager
City of Tamarac
7525 N.W. 88th Avenue
Tamarac, FL 33321
With a copy to the City Attorney at the following address. -
Hans Ottinot Law PA, City Attorney
Suite PMB-201
5944 Coral Ridge Drive
Corals Springs, FL 33076
TAMARAC
00_0 ^�.
The City For Your Life
City of Tamarac Purchasing and Contracts Division
Miami, FL 33131
Attn: John R. Herin, Jr.
CONTRACTOR
Name: Khan Builders, Inc.
Address:11240 SW 201h Street
City/State: Miramar, Florida 33025
FIN/EIN:83-3121367
Contract Licensee: CGC 1530017
Contact: Muhammad Khan
Email: mkhanQkhanbuildersinc com
Phone: 754-215-9650
19. TERMINATION
19.1 Termination for Convenience: This Agreement may be terminated by City for
convenience, upon seven (7) days of written notice by terminating party to the other
party for such termination in which event Contractor shall be paid its compensation for
services performed to termination date, including services reasonably related to
termination. In the event that Contractor abandons this Agreement or causes it to be
terminated, Contractor shall indemnify city against loss pertaining to this termination.
19.2 Default by Contractor: In addition to all other remedies available to the City, this
Agreement shall be subject to cancellation by the City for cause, should the Contractor
neglect or fail to perform or observe any of the terms, provisions, conditions, or
requirements herein contained, if such neglect or failure shall continue for a period of
thirty (30) days after receipt by Contractor of written notice of such neglect or failure.
Written notice of cancellation of this agreement shall state the date upon which the
Contractor shall cease all Work under this Contract and vacate the Project(s) site(s).
The Contractor shall, upon receipt of such notice, unless otherwise directed by the City:
Stop all Work on the Project(s) on the date specified in the notice (the effective date);
Take such action as may be necessary for the protection and preservation of the City's
materials and property; Cancel all cancelable orders for materials and equipment;
Assign to the City and deliver to the site, or any other location specified by the City, any
non -cancelable orders for materials and equipment that can not otherwise be used
except for Work under the Contract and have been specifically fabricated for the sole
purpose of the Work and not incorporated in the Work; Take no action that shall
increase the amounts payable by the City under the Contract Documents and take
reasonable measures to mitigate the City's liability under the Contract Documents. All
charts, drawings, reports, as-builts and other documents, including electronic
documents, related to Work authorized under the Contract, whether finished or not,
must be turned over to the City. Failure to timely deliver the documentation shall cause
to withhold any payments due without recourse by the Contractor until all
documentation is delivered to the City
20. AGREEMENT SUBJECT TO FUNDING
This agreement shall remain in full force and effect only as long as the expenditures provided
for in the Agreement have been appropriated by the City Commission of the City of Tamarac
22-20B Tamarac Community Center Restrooms Renovation
TAMAAC
The City For Your Life
City of Tamarac Purchasing and Contracts Division
in the annual budget for each fiscal year of this Agreement, and is subject to termination based
on lack of funding.
21. VENUE
This Agreement shall be governed by the laws of the State of Florida as now and hereafter in
force. The venue for actions arising out of this agreement is fixed in Broward County, Florida.
22. SIGNATORY AUTHORITY
The Contractor shall provide the City with copies of requisite documentation evidencing that
the signatory for Contractor has the authority to enter into this Agreement.
23. SEVERABILITY; WAIVER OF PROVISIONS
Any provision in this Agreement that is prohibited or unenforceable in any jurisdiction shall, as
to such jurisdiction, be ineffective to the extent of such prohibition or unenforceability without
invalidating the remaining provisions hereof or affecting validity or enforceability of such
provisions in any other jurisdiction. The non -enforcement of any provision by either party shall
not constitute a waiver of that provision nor shall it affect enforceability of that provision or of
the remainder of this Agreement.
24. UNCONTROLLABLE CIRCUMSTANCES
24.1 Neither the City nor Contractor shall be considered to be in default of this Agreement if
delays in or failure of performance shall be due to Uncontrollable Forces, the effect of
which, by the exercise of reasonable diligence, the non -performing party could not avoid.
The term "Uncontrollable Forces" shall mean any event which results in the prevention
or delay of performance by a party of its obligations under this Agreement and which is
beyond the reasonable control of the nonperforming party. It includes, but is not limited
to fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance,
sabotage, and governmental actions, such as delays in permitting due to outside
agencies, which are beyond the Contractor's control.
24.2 Neither party shall, however, be excused from performance if nonperformance is due to
forces, which are preventable, removable, or remediable, and which the nonperforming
party could have, with the exercise of reasonable diligence, prevented, removed, or
remedied with reasonable dispatch. The nonperforming party shall, within a reasonable
time of being prevented or delayed from performance by an uncontrollable force, give
written notice to the other party describing the circumstances and uncontrollable forces
preventing continued performance of the obligations of this Agreement.
25. MERGER; AMENDMENT
This Agreement constitutes the entire Agreement between the Contractor and the City, and
negotiations and oral understandings between the parties are merged herein. This Agreement
can be supplemented and/or amended only by a written document executed by both the
Contractor and the City.
26. NO CONSTRUCTION AGAINST DRAFTING PARTY
Each party to this Agreement expressly recognizes that this Agreement results from the
negotiation process in which each party was represented by counsel and contributed to the
drafting of this Agreement. Given this fact, no legal or other presumptions against the party
drafting this Agreement concerning its construction, interpretation or otherwise accrue to the
benefit of any party to the Agreement, and each party expressly waives the right to assert such
10
22-20B Tamarac Community Center Restrooms Renovation
TA►MAAC
The City For Your Life
City of Tamarac Purchasing and Contracts Division
a presumption in any proceedings or disputes connected with, arising out of, or involving this
Agreement.
27. CONTINGENT FEES
The Contractor warrants that it has not employed or retained any company or person, other
than a bona fide employee working solely for the Contractor to solicit or secure this Agreement
and that it has not paid or agreed to pay any person, company, corporation, individual or firm,
other than a bona fide employee working solely for the Contractor, any fee, commission,
percentage, gift or any other consideration contingent upon or resulting from the award or
making of this Agreement.
28. SCRUTINIZED COMPANIES - 287.135 AND 215.473
28.1 By execution of this Agreement, Contractor certifies that Contractor is not participating
in a boycott of Israel. Contractor further certifies that Contractor is not on the Scrutinized
Companies that Boycott Israel list, not on the Scrutinized Companies with Activities in
Sudan List, and not on the Scrutinized Companies with Activities in the Iran Petroleum
Energy Sector List, or has Contractor been engaged in business operations in Syria.
Subject to limited exceptions provided in state law, the City will not contract for the
provision of goods or services with any scrutinized company referred to above.
28.2 Submitting a false certification shall be deemed a material breach of contract. The City
shall provide notice, in writing, to Contractor of the City's determination concerning the
false certification. Contractor shall have five (5) days from receipt of notice to refute the
false certification allegation. If such false certification is discovered during the active
contract term, Contractor shall have ninety (90) days following receipt of the notice to
respond in writing and demonstrate that the determination of false certification was
made in error. If Contractor does not demonstrate that the City's determination of false
certification was made in error then the City shall have the right to terminate the contract
and seek civil remedies pursuant to Section 287,135, Florida Statutes, as amended
from time to time.
29. PUBLIC RECORDS
29.1 The CITY is a public agency subject to Chapter 119, Florida Statutes. The
CONTRACTOR shall comply with Florida's Public Records Law. Specifically,
CONTRACTOR shall:
29.1.1 Keep and maintain public records required by the CITY in order to perform the
service.
29.1.2 Upon request from the CITY, provide the public agency with a copy of the
requested records or allow the records to be inspected or copied within a
reasonable time at no cost to the CITY.
29.1.3 Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law
for the duration of the contract term and following completion of the Agreement
and any renewals thereof if CONTRACTOR does not transfer the records to the
CITY.
29.1.4 Upon completion of the Agreement, transfer, at no cost to the CITY, all public
records in possessiori of CONTRACTOR, or keep and maintain public records
required by the CITY to perform the service. If CONTRACTOR transfers all public
11
22-20B Tamarac Community Center Restrooms Renovation
TAMAR;AC
r��
The City For Your Life
City of Tamarac Purchasing and Contracts Division
records to the CITY upon completion of the Agreement, CONTRACTOR shall
destroy any duplicate public records that are exempt or confidential and exempt
from public records disclosure requirements. If CONTRACTOR keeps and
maintains public records upon completion of tha Agreement, CONTRACTOR
shall meet all applicable requirements for retaining public records. All records
stored electronically must be provided to the CITY, upon request from the CITY's
custodian of public records in a format that is compatible with the information
technology systems of the CITY.
29.2 During the term of this Agreement and any renewals, CONTRACTOR shall maintain all
books, reports and records in accordance with generally accepted accounting practices
and standards for records directly related to this contract.
30. E-VERIFY
As a condition precedent to entering into this Agreement, and in compliance with Section
448.095, Fla. Stat., Contractor and its subcontractors shall, register with and use the E-
Verify system to verify work authorization status of all employees hired after January 1,
2021. Contractor shall require each of its subcontractors to provide Contractor with an
affidavit stating that the subcontractor does not employ, contract with, or subcontract with
an unauthorized alien. Contractor shall maintain a copy of the subcontractor's affidavit as
part of and pursuant to the records retention requirements of this Agreement. City,
Contractor, or any sub contra ctor/subconsultant who has a good faith belief that a person
or entity with which it is contracting has knowingly violated Section 448.09(1), Fla. Stat.
or the provisions of this section shall terminate the contract with the person or entity. City,
upon good faith belief that a subcontractor knowingly violated the provisions of this
section; but Contractor otherwise complied, shall promptly notify Contractor and
Contractor shall immediately terminate the contract with the subcontractor.
An agreement or contract terminated under the provisions of this section is not a breach
of contract and may not be considered such. Any agreement or contract termination
under the provisions of this section may be challenged pursuant to Section 448.095(2)(d),
Fla. Stat. Contractor acknowledges that upon termination of this Agreement by the City
for a violation of this section by Contractor, Contractor may not be awarded a public
contract for at least one (1) year. Contractor further acknowledges that Contractor is liable
for any additional costs incurred by the City as a result of termination of any contract for
a violation of this section. Contractor or subcontractor shall insert in any subcontracts the
clauses set forth in this section; requiring the subcontractors to include these clauses in
any lower tier subcontracts. Contractor shall be responsible for compliance by any
subcontractor or lower tier subcontractor with the clauses set forth in this section.
31. CUSTODIAN OF RECORDS
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE
APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE
CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING
TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC
RECORDS AT:
1.2
22-20B Tamarac Community Center Restrooms Renovation
TAMARA
The City For Your Life
City of Tamarac Purchasing and Contracts Division
CITY CLERK
7525 NW 88TH AVENUE
ROOM 101
TAMARAC, FL 33321
(954) 597-3505
CITYCLERK@TAMARAC.ORG
13
22-20B Tamarac Community Center Restrooms Renovation
The City For Your Life
City of Tamarac Purchasin and Contracts Division
IN WITNESS WHEREOF, the parties have made and executed this Agreement on the respective
dates under each signature. CITY OF TAMARAC, signing by and through its Mayor and City Manager,
and CONTRACTOR, signing by and through its President duly authorized to execute same.
0� , �TA&,I ^
•U
W : ESTAB ;St D Q
ATTEST: ' O SEAL ° O
Kimberly Dillon, MC
City Clerk
oZOn� �2023
Date
ATTEST:
Signature of Corporate Secretary
Type/Print Name of Corporate Secy.
(CORPORATE SEAL)
�° d
SEAL`
-� ORN
CITY O TAMARAC
Mich Ile J. Gomez, May r
Da
ath en Gunn, City Manager
Date
v A to form and legal sufficiency:
y Attorney
Date
Khan Builders, Inc.
Company Name
Signature of President
Muhammed Khan
type/Print Name of President
rr p� 2
Da e
22-20B Tamarac Community Center Restrooms Renovation
14
TAMARAC
The city For Your Life
City of Tamarac Purchasing and Contracts Division
CORPORATE ACKNOWLEDGEMENT
STATE OF /-�b rr_cLC-t_
M
COUNTY OF /� a- 0 1,-;' �- J
I HEREBY CERTIFY that on this day, before me, an Officer duly authorized in the State aforesaid
and in the County aforesaid to take /z L ac
4. knowledgments, personally appeared fWk"f 1 r
President of '� , a Florida Corporation, to me known to be the person(s)
described in and who executed th�going instrument and acknowledged before me that he/she
executed the same.
WITNESS my hand and official seal this day of
ROSHAN
* *Notary Public, Stateate Of Of Florida
Commission No. HH 1561 22
�'""�My Commission Apires: 7/20/2025
n/o v e- ham, 20 2_ -)—
Signature of Notary Public
State of Florida at Large
4.a,LA�\ M,-,A
Print, Type or Stamp
Name of Notary Public
Personally, known to me or
❑ Produced Identification
Type of I.D. Produced
❑ DID take an oath, or
2 DID NOT take an oath.
15
22-20B Tamarac Community Center Restrooms Renovation