Loading...
HomeMy WebLinkAboutCity of Tamarac Resolution R-2016-0371 1 Temp. Reso. 12761 4/27/2016 Page 1 of 5 CITY OF TAMARAC, FLORIDA RESOLUTION NO. R-2016 37 A RESOLUTION OF THE CITY COMMISSION OF THE CITY OF TAMARAC, FLORIDA, AWARDING BID NO. 16- 05B TO AND APPROVING AN AGREEMENT WITH MBR CONSTRUCTION, INC. FOR THE CONSTRUCTION OF CITYWIDE BUFFER WALL PROJECT PHASE I, IN ACCORDANCE WITH BID NO. 16-05B FOR A CONTRACT AMOUNT OF $1,128,075.82; A CONTINGENCY IN AN AMOUNT OF $112,807.58 WILL BE ADDED TO THE PROJECT ACCOUNT, FOR A TOTAL PROJECT BUDGET OF $1,240,883.40; AUTHORIZING AN EXPENDITURE FROM THE APPROPRIATE ACCOUNTS; PROVIDING FOR CONFLICTS; PROVIDING FOR SEVERABILITY; AND PROVIDING FOR AN EFFECTIVE DATE. WHEREAS, as part of the recently completed Major Arterial Corridor Study, it was determined that the City will move forward with the Buffer Wall component of the Study, which includes the design and construction of neighborhood buffer wall treatments for various parts of the City; and WHEREAS, the Tamarac Lakes South Buffer Wall Project is considered Phase I of this program; and WHEREAS, the project location is generally located on the south side of Commercial Boulevard between NW 25th Terrace and NW 31 St Avenue, and WHEREAS, the Tamarac Lakes South Buffer Wall Project Phase I consists of approximately 3,500 Linear Feet of a precast system buffer wall, together with associated landscaping and irrigation improvements, and Temp. Reso. 12750 2/24/2016 Page 2 of 5 WHEREAS, the construction element for Bid No. 16-05B includes, but is not limited to, concrete foundations, retaining walls, concrete columns and precast wall panels, together with associated landscaping, hardscape, irrigation and pavement marking improvements. WHEREAS, the City of Tamarac publicly advertised Bid No. 16-05B Citywide Buffer Wall Project Phase I on February 9, 2016, incorporated herein by reference and on file in the office of the City Clerk; and WHEREAS, on March 8th, 2016, the City of Tamarac received two (2) proposals for the Citywide Buffer Wall Project Phase I, a bid tabulation is hereto attached as "Exhibit 1 "; and WHEREAS, staff determined the lowest responsive and responsible bidder to be MBR Construction, Inc.; and WHEREAS, MBR Construction, Inc. possesses the required knowledge and experience to construct Citywide Buffer Wall Project Phase I and has agreed to the Terms and Conditions, Special Conditions, and Technical Specifications of Bid No. 16- 05B, and WHEREAS, available funds for the balance of said buffer wall installation exist in the Corridor Improvement Fund; and WHEREAS, it is the recommendation of the Public Services Director and Purchasing and Contracts Manager that the appropriate City officials award Bid No. 16- 05B and execute the Agreement with MBR Construction, Inc. for the Citywide Buffer Wall Project Phase I along south side of Commercial Boulevard, between NW 25th Terrace and NW 31st Avenue as "Exhibit #2"; incorporated herein and made a specific Temp. Reso. 12750 2/24/2016 Page 3 of 5 part of this resolution; and WHEREAS, the City Commission of the City of Tamarac, Florida deems it to be in the best interest of the citizens and residents of the City of Tamarac to award Bid No. 16-05B and execute the agreement for the Citywide Buffer Wall Project Phase I with MBR Construction, Inc. for a contract cost of $1,128,075.82 and a contingency in the amount of $112,807.58, for a total project budget of $1,240,883.40. NOW, THEREFORE, BE IT RESOLVED BY THE CITY COMMISSION OF THE CITY OF TAMARAC, FLORIDA THAT: SECTION 1: The foregoing "WHEREAS" clauses are hereby ratified and confirmed as being true and correct and are hereby made a specific part of this Resolution upon adoption hereof. All Exhibits attached hereto are incorporated herein and made a specific part of this Resolution. SECTION 2: The City Commission HEREBY awards Bid No. 16-05B to MBR Construction, Inc. and approves an Agreement between the City of Tamarac and MBR Construction, Inc. ("The Agreement") and the appropriate City officials are hereby authorized to execute the Agreement, hereto attached as "Exhibit 2", to provide for the Citywide Buffer Wall Project Phase I. E Temp. Reso. 12750 2/24/2016 Page 4 of 5 SECTION 3: An expenditure for a contract cost of $1,128,075.82 and a contingency in the amount of $112,807.58, for a total project budget of $1,240,883.40 for said purpose is hereby approved. SECTION 4: Funding for the Citywide Buffer Wall Project Phase I for a contract cost of $1,128,075.82 and a contingency in the amount of $112,807.58, for a total project budget of $1,240,883.40 is available in Project Number GP14K in the Corridor Improvement Fund. SECTION 5: The City Manager or his designee is hereby authorized to approve and initiate Change Orders in amounts not to exceed $65,000.00 per Section 6-147 of the City Code, and close the contract award, which includes but is not limited to, making final payment and releasing bonds per Section 6-149 of the City Code, when the work has been successfully completed within the terms, conditions and pricing of the agreement. SECTION 6: All Resolutions or parts of Resolutions in conflict herewith are hereby repealed to the extent of such conflict. SECTION 7: If any clause, section, other part or application of this Resolution is held by any court of competent jurisdiction to be unconstitutional or invalid, in part or application, it shall not affect the validity of the remaining portions or applications of this Resolution. E 1 1 Temp. Reso. 12750 2/24/2 016 Page 5 of 5 SECTION 8: This Resolution shall become effective immediately upon its passage and adoption. PASSED, ADOPTED AND APPROVED this a7 day of 6p� 2016. ATTEST: PATRCITY CLERK ICIA I HEREBY CERTIFY THAT I HAVE APPROVED THIS RESOLUTION AS TO FORM Vie' . '.6 1 ; 7 1 b SA UEL S. GOREN CITY ATTORNEY —1 &M� :::: HA RY DRESSLER MAYOR RECORD OF COMMISSION VOTE: MAYOR DRESSLER DIST 1: COMM. BUSHNELL DIST 2: COMM. GOMEZ DIST 3: VICE MAYOR GLASSER DIST 4: COMM. PLACKO x z n O z (D rD r) 0 N O C 3 (D 3 rr N (D m (D N C a- 3 K N a z n z 0 z M m o_ n n O 3 o 3 rt � C O n r! p O 7 W _ 3 f1 0 m A � x x c C. x x a cp e x x ?a� a x x aa? x x a� °ono x x ha�Q �o 0 x x Q ON x xJ�� e?� 7J x x a x x 3? Qo Cc, x x �aQQ oQ 3 .off x x .ti 4, ON, F+ �9 N O 00 F+ O O � V Ul 00 N t J n CL m 00 c Zhh m a m � � o = C N rn r+ c O � o0 0 V v {A m pest. LETTER OF TRANSMITTAL TO: City of Tamarac ATTN: Andrew Rozwadowski DATE: 03/25/2016 JOB: Citywide Buffer Walls Phase 1 We transmit the following documentation as indicated: for approval for review and comment for your file x as requested other 2 Copies of contract, W-9, COI FROM: Mike Boss 1020 NW 51st Street, Fort Lauderdale, FL 33309 P 954.486.8404 F 954.486.9579 MBRconstruction.com LIC.#CGCA08949 #CGC1512261 Bid No. 16-05 B CITYWIDE BUFFER WALLS - PHASE I AGREEMENT BETWEEN THE CITY OF TAMARAC AND MBR Construction, Inc. THIS AGREEMENT is made and entered into this � day ofe 20& by and between the City of Tamarac, a municipal corporation with principal offices located at 7525 N.W. 88th Ave., Tamarac, FL 33321 (the "CITY") and MBR Construction, Inc., a corporation with principal offices located at 1020 NW 51 st Street Fort Lauderdale FL 33309 (the "Contractor") to provide for the construction and installation of the Citywide Buffer Walls — Phase I. Now therefore, in consideration of the mutual covenants hereinafter set forth, the City and Contractor agree as follows: 1) The Contract Documents The Contract Documents consist of this Agreement, Bid Document No. 16-05 — Citywide Buffer Wall Installation — Phase I, including all conditions therein, (General Terms and Conditions, Special Conditions and/or Special Provisions), drawings, Technical Specifications, all addenda, the Contractor's bid/proposal included herein, and all modifications issued after execution of this Agreement. These contract documents form the Agreement, and all are as fully a part of the Agreement as if attached to this Agreement or repeated therein. In the event that there is a conflict between Bid No. 16-05 B as issued by the City, and the Contractor's Proposal, Bid No. 16-05 B as issued by City shall take precedence over the Contractor's Proposal. Furthermore, in the event of a conflict between this document and any other Contract Documents, this Agreement shall prevail. 2) The Work 2.1. The Contractor shall perform all work for the City required by the contract documents as set forth below: 2.1.1 Contractor shall furnish all labor, materials, and equipment necessary to complete the scope of work, as outlined in the contract documents. 2.1.2 Contractor shall supervise the work force to ensure that all workers conduct themselves and perform their work in a safe and professional manner. Contractor shall comply with all OSHA safety rules and regulations in the operation of equipment and in the performance of the work. Contractor shall at all times have a competent field supervisor on the job site to enforce these policies and procedures at the Contractor's expense. 2.1.3 Contractor shall provide the City with seventy-two (72) hours written notice prior to the beginning of work under this Agreement and prior to any schedule change with the exception of changes caused by inclement weather. 2.1.4 Contractor shall comply with any and all Federal, State, and local laws and regulations now in effect, or hereinafter enacted during the term of this Agreement, which are applicable to the Contractor, its employees, agents or subcontractors, if any, with respect to the work and services described herein. 3) Insurance 3.1. Contractor shall obtain at Contractor's expense all necessary insurance in such form and amount as specified in the original bid document or as required by the City's Risk and Safety Manager before beginning work under this Agreement including, but not limited to, Workers' Compensation, Commercial General Liability, Builder's Risk and all other insurance as required by the City, including Professional Liability when appropriate. Contractor shall maintain such insurance in full force and effect during the life of this Agreement. Contractor shall provide to the City's Risk and Safety Manager certificates of all insurances required under this section prior to beginning any work under this Agreement. The Contractor will ensure that all subcontractors comply with the above guidelines and will retain all necessary insurance in force throughout the term of this agreement. 3.2. Contractor shall indemnify and hold the City harmless for any damages resulting from failure of the Contractor to take out and maintain such insurance. Contractor's Liability Insurance policies shall be endorsed to add the City as an additional insured. Contractor shall be responsible for payment of all deductibles and self-insurance retentions on Contractor's Liability Insurance policies. Insurance limits are outlined below: Insurance Requirements Line of Business/ Coverage Occurrence I Aggregate Limits Commercial General Liability Including: Premises/Operations Contractual Liability Personal Injury Explosion, Collapse, Underground Hazard $1,000,000 $1,000,000 Products/Completed Operation Broad Form Property Damage Cross Liability and Severability of Interest Clause Automobile Liability $1,000,000.00 1 $1,000,000.00 Workers' Compensation & Statutory Employer's Liability 4) Time of Commencement and Substantial Completion 4.1 The work to be performed under this Agreement shall be commenced after City execution of the Agreement and not later than ten (10) days after the date that Contractor receives the City's Notice to Proceed. The work shall be completed within Two -Hundred Forty (240) Days from issuance of City's Notice to Proceed, subject to any permitted extensions of time under the Contract Documents. For the purposes of this Agreement, completion shall mean the issuance of final payment. 4.2 During the pre -construction portion of the work hereunder, the parties agree to work diligently and in good faith in performing their obligations hereunder, so that all required permits for the construction portion of the work may be obtained by the City in accordance with the Schedule included in the Contract Documents. In the event that any delays in the pre -construction or construction portion of the work occur, despite the diligent efforts of the parties hereto, and such delays are the result of force majeure or are otherwise outside of the control of either party hereto, then the parties shall agree on an equitable extension of the time for substantial completion hereunder and any resulting increase in general condition costs. 5) Contract Sum The Contract Sum for the above work is One Million One Hundred Twenty Eight Thousand Seventy Five Dollars and Eighty Two cents ($1,128,075.82). 6) Payments Payment will be made monthly for work that has been completed, inspected and properly invoiced.' A retainage of ten. percent (10%) will be deducted" from monthly payments until 50% of the project is complete. Retainage will be reduced to five percent (5%) thereafter. Retainage monies will be released upon satisfactory completion and final inspection of the work. Invoices must bear the project name, project number, bid number and purchase order number. City has up to thirty (30) days to review, approve and pay all invoices after receipt. The Contractor shall invoice the City and provide a written request to the City to commence the one (1) year warranty period. All necessary Releases of Liens and Affidavits and approval of Final Payments shall be processed before the warranty period begins. All payments shall be governed by the Florida Prompt Payment Act, F.S., Part VII, Chapter 218. 7) Remedies 7.1 Damages: The City reserves the right to recover any ascertainable actual damages incurred as a result of the failure of the Contractor to perform in accordance with the requirements of this Agreement, or for losses sustained by the City resultant from the Contractor's failure to perform in accordance with the requirements of this Agreement. 7.2 Correction of Work: If, in the judgment of the City, work provided by the Contractor does not conform to the requirements of this Agreement, or if the work exhibits poor workmanship, the City reserves the right to require that the Contractor correct all deficiencies in the work to bring the work into conformance without additional cost to the City, and / or replace any personnel who fail to perform in accordance with the requirements of this Agreement. The City shall be the sole judge of non- conformance and the quality of workmanship. 8) Change Orders 8.1 Without invalidating the contract, without any monetary compensation, and without notice to any surety, the City reserves and- shall have the right to make increases, decreases or other changes to the work as may be considered necessary or desirable to complete the proposed construction in a satisfactory manner. The Contractor shall not start work pursuant to a change order until the change order setting forth the adjustments is approved by the City, and executed by the City and Contractor. Once the change order is so approved, the Contractor shall promptly proceed with the work. All Change Orders shall include overhead and profit, not to exceed five percent (5%) and five percent (5%) respectively. 8.2 The Contract Price constitutes the total compensation (subject to authorized adjustments, if applicable) payable to the Contractor for performing the work. All duties, responsibilities and obligations assigned to or undertaken by the Contractor shall be at Contractor's expense without change in the Contract Price or Time except as approved in writing by the City. 8.3 The Contract Price and/or Time may only be changed by a Change Order. A fully executed change order for any extra work must exist before such extra work is begun. Any claim for an increase or decrease in the Contract Price shall be based on written notice delivered by the party making the claim to the other party promptly (but in no event later than 15 days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. The amount of the claim with supporting data shall be delivered (unless the City allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by claimant's written statement that the amount -claimed covers all known amounts to which the claimant is entitled as a result of the occurrence of said event. No claim for an adjustment in the Contract Price will be valid if not submitted in accordance with this Paragraph. 8.4 The Contract Time may only be changed by a Change Order. A fully executed change order must exist prior to extension of the contract time. 8.5 Any claim for an extension of the Contract Time shall be based on written notice delivered by the party making the claim to the other party no later than fifteen (15) days after the occurrence of the event giving rise to the claim. Notice of the extent of the claim shall be delivered with supporting data and stating the general nature of the claim. Contractor hereby agrees to waive rights to recover any lost time or incurred costs from delays unless Contractor has given the notice and the supporting data required by this Paragraph. 8.6 Extensions of time shall be considered and will be based solely upon the effect of delays to the work as a whole. Extensions of time shall not be granted for delays to the work, unless the Contractor can clearly demonstrate that such delays did or will, in fact, delay the progress of work as a whole. Time extensions shall not be allowed for delays to parts of the work that are not on the critical path of the project schedule. Time extensions shall not be granted until all float or contingency time, at the time of delay, available to absorb specific delays and associated impacts is used. 8.7 In the event satisfactory adjustment cannot be reached by the City and the Contractor for any item requiring a change in the contract, and a change order has not been issued, the City reserves the right at its sole option to terminate the contract as it applies to these items in question and make such arrangements as the City deems necessary to complete the work. The cost of any work covered by a change order for an increase or decrease in the contract price shall be determined by mutual acceptance of a Guaranteed Maximum Price by the City and Contractor. If notice of any change in the contract or contract time is required to be given to a surety by the provisions of the bond, the giving of such notice shall be the Contractor's responsibility, and the amount of each applicable bond shall be adjusted accordingly. The Contractor shall furnish proof of such adjustment to the City Failure of the Contractor to obtain such approval from the Surety may be a basis for termination of this Contract by the City. 9) No Damages for Delays ALL TIME LIMITS STATED IN THE CONTRACT DOCUMENTS ARE OF THE ESSENCE OF THE AGREEMENT. EXCEPT AS PROVIDED HEREIN, NO CLAIM FOR DAMAGES OR ANY CLAIM OTHER THAN FOR AN EXTENSION OF TIME SHALL BE MADE OR ASSERTED AGAINST THE CITY BY REASON OF ANY DELAYS. Contractor shall not be entitled to an increase in the construction cost or payment. or compensation of any kind from City for direct, indirect, consequential, impact or other costs, expenses or damages including but no limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference or hindrance from any cause whatsoever, whether such delay, disruption, interference be reasonable or unreasonable, foreseeable or unforeseeable, or avoidable or unavoidable; provided, however, that this provision shall not preclude recovery of damages by Contractor for hindrances or delays due solely to fraud, bad faith or active interference on the part of City or its agents. In addition, if Contractor is delayed at any time in the progress of the Work by an act or. neglect of the City's employees, or separate contractors employed by the City, or by changes ordered in the Work, or by delay authorized by the City pending arbitration, then the Contract Time shall be reasonably extended by Change Order, and the Guaranteed Maximum Price shall be reasonably increased by Change Order in order to equitably increase the general conditions component of the Guaranteed Maximum Price. Furthermore, if Contractor is delayed at any time in the progress of the Work by labor disputes, fire, unusual delay in deliveries, adverse weather conditions not reasonably anticipated, unavoidable casualties or other causes beyond the Contractor's control, or by other causes which the City and Contractor agree may justify delay, then the Contract Time shall be reasonably extended by Change Order. Otherwise, Contractor shall be entitled only to extensions of the Contract Time as the sole and exclusive remedy for such resulting delay, in accordance with and to that extent specifically provided above. No extension of time shall be granted for delays resulting from normal weather conditions prevailing in the area as defined by the average of the last ten (10) years of weather data as recorded by the United States Department of Commerce, National Oceanic and Atmospheric Administration at the Fort Lauderdale Weather Station. 10) Waiver of Liens Prior to final payment of the Contract Sum, a final waiver of lien shall be submitted by all suppliers, subcontractors, and/or Contractors who worked on the project that is the subject of this Agreement. Payment of the invoice and acceptance of such payment by the Contractor shall release City from all claims of liability by Contractor in connection with the agreement. 11) Warranty Contractor warrants the work against defect for a period of one (1) year from the date of final payment. In the event that defect occurs during this time, Contractor shall perform such steps as required to remedy the defects. Contractor shall be responsible for any damages caused by defect to affected area or to interior structure. The one (1) year warranty period does not begin until approval of final payment for the entire project, and the subsequent release of any Performance or Payment Bonds, which may be required by the original bid document. 12) Indemnification 12.1 The Contractor shall indemnify and hold harmless the City, its elected and appointed officials, employees, and agents from any and all claims, suits, actions, damages, liability, and expenses (including attorneys' fees) in connection with loss of life, bodily or personal injury, or property damage, including loss of use thereof, directly or indirectly caused by, resulting from, arising out of or occurring in connection with the operations of the Contractor or its officers, employees, agents, subcontractors, or independent Contractors, excepting only such loss of life, bodily or personal injury, or property damage solely attributable to the gross negligence or willful misconduct of the City or its elected or appointed officials and employees. The above provisions shall survive the termination of this Agreement and shall pertain to any occurrence during the term of this Agreement, even though the claim may be made after the termination hereof. 12.2 The City and Consultant recognize that various provisions of this Agreement, including but not limited to this Section, provide for indemnification by the Consultant and requires a specific consideration be given there for. The Parties therefore agree that the sum of Ten Dollars and 00/100 ($10.00), receipt of which is hereby acknowledged, is the specific consideration for such indemnities, and the providing of such indemnities is deemed to be part of the specifications with respect to the services to be provided by Consultant. Furthermore, the City and Consultant understand and agree that the covenants and representations relating to this indemnification provision shall serve the term of this Agreement and continue in full force and effect as to the City's and the Consultant's responsibility to indemnify. 12.3 Nothing contained herein is intended nor shall be construed to waive City's rights and immunities under the common law or Florida Statutes 768.28, as amended from time to time 13) Non -Discrimination & Equal Opportunity Employment During the performance of the Contract, the Contractor and its subcontractors shall not discriminate against any employee or applicant for employment because of race, color, sex including pregnancy, religion, age, national origin, marital status, political affiliation, familial status, sexual orientation, gender identity and expression, or disability if qualified. The Contractor will take affirmative action to ensure that employees and those of its subcontractors are treated during employment, without regard to their race, color, sex including pregnancy, religion, age, national origin, marital status, political affiliation, familial status, sexual orientation, gender identity or expression, or disability if qualified. Such actions must include, but not be limited to, the following: employment, promotion; demotion or transfer; recruitment or recruitment advertising, layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. The Contractor and its subcontractors shall agree to post in conspicuous places, available to its employees and applicants for employment, notices to be provided by the contracting officer setting forth the provisions of this nondiscrimination clause. The Contractor further agrees that he/she will ensure that all subcontractors, if any, will be made aware of and will comply with this nondiscrimination clause. 14) Independent Contractor This Agreement does not create an employee/employer relationship between the Parties. It is the intent of the Parties that the Contractor is an independent contractor under this Agreement and not the City's employee for any purposes, including but not limited to, the application of the Fair Labor Standards. Act minimum wage and overtime payments, Federal Insurance Contribution Act, the Social Security Act, the Federal Unemployment Tax Act, the provisions of the Internal Revenue Code, the State Worker's Compensation Act, and the State Unemployment Insurance law. The Contractor shall retain sole and absolute discretion in the judgment of the manner and means of carrying out Contractor's activities and responsibilities hereunder provided, further that administrative procedures applicable to services rendered under this Agreement shall be those of Contractor, which policies of Contractor shall not conflict with City, State, or United States policies, rules or regulations relating to the use of Contractor's funds provided for herein. The Contractor agrees that it is a separate and independent enterprise from the City, that it had full opportunity to find other business, that it has made its own investment in its business, and that it will utilize a high level of skill necessary to perform the work. This Agreement shall not be construed as creating any joint employment relationship between the Contractor and the City and the City will not be liable for any obligation incurred by Contractor, including but not limited to unpaid minimum wages and/or overtime premiums. 15) Assignment and Subcontracting Contractor shall not transfer or assign the performance required by this Agreement without the prior consent of the City. This Agreement, or any portion thereof, shall not be subcontracted without the prior written consent of the city. 16) Notice Whenever either party desires or is required under this Agreement to give notice to any other party, it must be given by written notice either delivered in person, sent by U.S. Certified Mail, U.S. Express Mail, air or ground courier services, or by messenger service, as follows: CITY City Manager City of Tamarac 7525 N.W. 88th Avenue Tamarac, FL 33321 With a copy to the City Attorney at the following address: Goren, Cherof, Doody & Ezrol, P.A. 3099 East Commercial Blvd., Suite 200 Fort Lauderdale, FL 33308 CONTRACTOR MBR Construction. Inc. 1020 NW 51 st Street Fort Lauderdale FL 33309 954486-84041 954-486-9579 mboss@mbrconstruction.com 17) Termination 17.1 Termination for Convenience: This Agreement may be terminated by the City for convenience, upon seven (7) days of written notice by City to the Contractor for such termination in which event the Contractor shall be paid its compensation for services performed to termination date, including services reasonably related to termination. In the event that the Contractor abandons this Agreement or causes it to be terminated, Contractor shall indemnify the city against loss pertaining to this termination. 17.2 Default by Contractor: In addition to all other remedies available to the City, this Agreement shall be subject to cancellation by the City for cause, should the Contractor neglect or fail to perform or observe any of the terms, provisions, conditions, or requirements herein contained, if such neglect or failure shall continue for a period of thirty (30) days after receipt by Contractor of written notice of such neglect or failure. 18) Public Records 18.1 The City of Tamarac is a public agency subject to Chapter 119, Florida Statutes. The Contractor shall comply with Florida's Public Records Law. Specifically, the Contractor shall: 18.1.1 Keep and maintain public records that ordinarily and necessarily would be required by the City in order to perform the service; 18.1.2 Provide the public with access to such public records on the same terms and conditions that the City would provide the records and at a cost that does not exceed that provided in chapter 119, Fla. Stat., or as otherwise provided by law; 18.1.3 Ensure that public records that are exempt or that are confidential and exempt from public record requirements are not disclosed except as authorized by law; and 18.1.4 Meet all requirements for retaining public records and transfer to the City, at no cost, all public records in possession of the contractor upon termination of the contract and destroy any duplicate public records that are exempt or confidential and exempt. All records stored electronically must be provided to the City in a format that is compatible with the information technology systems of the agency. 18.2 The failure of Contractor to comply with the provisions set forth in this Article shall constitute a Default and Breach of this Agreement and the City shall enforce the Default in accordance with the provisions set forth in Article 17 "Termination" herein. 19) Agreement Subject to Funding This agreement shall remain in full force and effect only as long as the expenditures provided for in the Agreement have been appropriated by the City Commission of the City of Tamarac in the annual budgef for each fiscal year of this Agreement, and is subject to termination based on lack of funding. 20) Venue This Agreement shall be governed by the laws of the State of Florida as now and hereafter in force. The venue for actions arising out of this agreement is fixed in Broward County, Florida. 21) Signatory Authority The Contractor shall provide the City with copies of requisite documentation evidencing that the signatory for Contractor has the authority to enter into this Agreement. 22) Severability; Waiver of Provisions Any provision in this Agreement that is prohibited or unenforceable in any jurisdiction shall, as to such jurisdiction, be ineffective to the extent of such prohibition or unenforceability without invalidating the remaining provisions hereof or affecting the validity or enforceability of such provisions in any other jurisdiction. The non- enforcement of any provision by either party shall not constitute a waiver of that provision nor shall it affect the enforceability of that provision or of the remainder of this Agreement. 23) Uncontrollable Circumstances 23.1 Neither the City nor Contractor shall be considered to be in default of this Agreement if delays in or failure of performance shall be due to Uncontrollable Forces, the effect of which, by the exercise of reasonable diligence, the non -performing party could not avoid. The term "Uncontrollable Forces" shall mean any event which results in the prevention or delay of performance by a party of its obligations under this Agreement and which is beyond the reasonable control of the nonperforming party. It includes, but is not limited to fire, flood, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance, sabotage, and governmental actions. 23.2 Neither party shall, however, be excused from performance if nonperformance is due to forces, which are preventable, removable, or remediable, and which the nonperforming party could have, with the exercise of reasonable diligence, prevented, removed, or remedied with reasonable dispatch. The nonperforming party shall, within a reasonable time of being prevented or delayed from performance by an uncontrollable force, give written notice to the other party describing the circumstances and uncontrollable forces preventing continued performance of the obligations of this Agreement. 24) Merger; Amendment This Agreement constitutes the entire Agreement between the Contractor and the City, and negotiations and oral understandings between the parties are merged herein. This Agreement can be supplemented and/or amended only by a written document executed by both the Contractor and the City. 25) No Construction Against Drafting Party Each party to this Agreement expressly recognizes that this Agreement results from the negotiation process in which each party was represented by counsel and contributed to the drafting of this Agreement. Given this fact, no legal or other presumptions against the party drafting this Agreement concerning its construction, interpretation or otherwise accrue to the benefit of any party to the Agreement, and each party expressly waives the right to assert such a presumption in any proceedings or disputes connected with, arising out of, or involving this Agreement. Remainder of Page Intentionally Blank IN WITNESS WHEREOF, the parties have made and executed this Agreement on the respective dates under each signature. CITY OF TAMARAC, signing by and through its Mayor and City Manager, and CONTRACTOR, signing by and through its duly authorized to execute same. ATTEST: atricia A. Teufel, CM City Clerk /,/J,4tI�' Date Cift OF TAMARAC Harry Ordssler, Mayor 'Vichael C. Cernech, City Manager Date Appro ed as to form and legal sufficiency: j 4 mu'v City/Attorney- Date AT - MBR Construction. Inc. Com Si4a-tu orpora a Secretary ignatur President/Owner Type/Print Na a of Corporate Secy. Type/Print Name of President/Owner (CORPORATE SEAL) Date CORPORATE ACKNOWLEDGEMENT STATE OF f COUNTY OF fawn I HEREBY CERTIFY that on this day, before me, an Officer duly authorized in the State aforesaid and in the County aforesaid to take acknowledgments,. personally appeared 5 , of M 6P, C 4cj� T U e- ) c— a Corporation, to me known to be the person(s) described in and who executed the foregoing instrument and acknowledged before me that he/she executed the same. WITNESS my hand and official seal this day of n'11-�YA, 20 16 FWEWCOLE- ignature of Notary Public r otary PW* - State of Florida Comission #E FF 119689 State of Florida at Large y Comm. Expires Auq ?8 ?018 Print, Type or Stamp Name of Notary Public 19----Personally known to me or ❑ Produced Identification Type of I.D. Produced ❑ DID take an oath, or [0---PJID NOT take an oath. MBRCO-2 OP ID: N8 ACORoS CERTIFICATE OF LIABILITY INSURANCE DATE (MMIDD/YYYY) 02/22/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Brown & Brown of Florida, Inc. 1201 W Cypress Creek Rd # 130 P.O. Box 5727 Ft Lauderdale, FL 33310-5727 Andrew Noye, CIC, CRIS CONTNAMEACT Andrew Noye, CIC, CRIS PHONE 954-776-2222 a,c No : 954-776-4446 AIC No Ell: E-MAIL ADDRESS: INSURER(S) AFFORDING COVERAGE NAIC# INSURER A:Bridgefield Employers Ins. Co+ 10701 INSURED MBR Construction, Inc. INSURER B: Gemini Insurance Co.+ 10833 Attn: Ron / Mike Boss 1020 NW 51 Street Ft. Lauderdale, FL 33309 INSURER C : North River Insurance Company+ 21105 INSURER D :Houston Casualty Company+ 42374 INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF MM,DD/YYYY POLICY EXP MM/DD/YYYY LIMITS B X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS -MADE OCCUR ❑X VFGPOO17302016 02/22/2016 02/22/2017 DAMAG O RENTED PREMISES Ea ocwn-ence $ 100,000 MED EXP (Any one person) $ 5,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 PRODUCTS -COMP/OPAGG $ 2,000,000 PRO - POLICY JECT PRO LOC Emp Ben. $ 1,000,000 OTHER: AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT Ea accident $ BODILY INJURY (Per person) $ ANY AUTO BODILY INJURY (Per accident) $ ALL OWNED SCHEDULED AUTOS AUTOS NON -OWNED HIRED AUTOS AUTOS PeOr ac TY DAMAGE $ X UMBRELLA LIAR X OCCUR EACH OCCURRENCE $ 6,000,000 AGGREGATE $ 12,000,000 C EXCESS LIAB CLAIMS -MADE 5821047297 02/22/2016 02/22/2017 DED I X I RETENTION $ 0 $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE Y /❑N 83051338 08/05/2015 08/05/2016 PER OTH- S TATUTE ER E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYEE $ 1,000,000 OFFICER/MEMBER EXCLUDED? (Mandatory in NH) N I A E.L. DISEASE- POLICY LIMIT $ 1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below D Professional HCC14636072016 02/22/2016 02/22/2017 EachClaim 1,000,000 Liability Aggregate 1,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) TAMACTY City of Tamarac Building Department 6011 Nob Hill Road 1st Fir Tamarac, FL 33321-6200 CAN SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATI V E ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014/01) The ACORD name and logo are registered marks of ACORD OF LIABILITY INSURANCE on Kh 8, Nava Insurance Agency, Inc. 4720 N. Federal Hwy. j Ft Lauderdale, FL ,M0& INSUREOi -. MBR CQNSTRUCTION, INC. 1020 NW 51 ST. FT. LAUDERDALE, FL 33309.3134 \rVYGiV� GJ M. ,q t IF .v THIS IS TO CERTIFY THAT THE POL101E3 OF INSURANCE LIFMD BELOW HAVE BEEN ISSUE- TO Tji if INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTIMTHSTANDING ANY REQUIREMENT, TEM4 OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO VMMH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, TH8 INSURANCE AFFORDED BY THE POLICIES DESCRIBED HPREIN IS SURJ20T TO ALL THE TIMMS, MIL10IONSANO CONDITIONS OF SUCH POLICIR8; LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAIDCLAIMS. _ JM TYPOOPINSURANOE ADDL SVW fWQYNUMBER Irdonffib UNITS GENERALUAIMUTY O(MMERCIAWENERAL EIAEIUTY. CLAIM -MAOR t��.""Ij OCCLIR• EACHOCCMRRENCE b f MED EkP (An n,,,oeU f $ P&R80NALdAtfYINJURY i �_„� .. GENERALAGGREOATE, b OEN'LAOMOATEUMITAPPLIESFEW POLICY P LOC ' PA00UCTa-CoMPicPA103 W Y f AUTOMONLELIA�ITY K X � Y. AWAM6 ALLOVW40AVTOS SMOULEOAM OS HINEDAUTOS. NONOAMTOS Y 1377823 0153161 03(041Z616 02112016 69/6412016 001E1f2018 (FA kddem) CCMdNEOSNtCiLEUMTf - — b 1,000,D00 8001LYINJURY(Porpe,wn) 11 BOHLYMURY(Par ecdd$4 : PROPERTY DAMAGE tParaod&6RQ . : -- b f UMBRELLAUAe Mwas UA9 'OCCUR............. GLAIMf.MAOE DE EACHC+CCtl12RRPbS b AWRIMATE OED1aTI�E 1 . i WORMS AND RMPLAYERV LUUiBJTY ANYPROPMETCRIPARTNRRMXEOU' (OlPFICSwmwl�pE{R�EXOLU0601 - 1(recdpa sunder NrA E.L:EACMACCIOfNY f Vt. CISEASE-9AEMPLOYE f EL DISEASE -POLICY LIMIT f DESCRIPTION 0P OPERATIONB tLOCAT10NbI+/EHICLEb IgW eM AGORDIO{ AddNMnal Remorb SmedWh RUIM spite lE ngUlM), CI of Tamarac eHOULO ANY Of THE AVovj MSCR18E0 PO00118 RE CANCELLED 9EFORH TN[ City GVIV01ION DATE THEREOF, NOTICB WILL er DELIVER90 IN ACCORDANCE WITH THE Building Department POUCYPROVIEIONB. 6011 Nab Hill Road 1stsFir Tamarac, FL 33321-6200; AV"F11 aDRSFUSINTATNB h6= IID 1060. 2009 ACORD CORPOMT10N AB rlghts reserved;, —A iw..,. era rankeereH -.r4s Af a pnRtyi 1001480 132849.4 02-11-2010