Loading...
HomeMy WebLinkAboutCity of Tamarac Resolution R-85-067Ll 1 1 1 2 3 4 5 7 8 9 10 11 12 "3 15 16 17 18 19 20 1 22 23 24 25 26 27 28 29 30 32 33 34 Introduced by Temp. Reso. #3525 CITY OF TAMARAC, FLORTDA RESOLUTION NO. R-85- 6 7 A RESOLUTION AWARDING A BID AND AUTHORIZING EXECUTION OF AN AGREEMENT WITH GEORGE FET,D AND ASSOCIATES, INC., FOR THE TAMARAC PARK SATELLITE RECREATION BUILDING (BID #84-35); AND PROVIDTNG-AN EEFECTIYE DATE, WHEREAS, bids for the construction of a Satellite Recreation Building were advertised in the Fort Lauderdale News/Sun Sentinel, a newspaper of general circulation in Broward County, on December 13, 14, 15, 16, 18, 19, 20 and 21, 1984; and WHEREAS, bids were opened on January 18, 1985; and WHEREAS, the bidding documents called for subcontract bids and none were received; and WHEREAS, on February 13, 1985, the City Council, upon the recommendation of the City Manager, authorized the City Manager to negotiate with the general contractor who was low bidder for this project; and WHEREAS, the City Manager has made recommendation for bid award to the City Council. NOW, THEREFORE, BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF TAMARA.C, FLORIDA.: SECTION 1: That the bid of George Feld and Associates, Inc., in the negotiated amount of $195,950.00, is hereby ACCEPTED and APPROVED. SECTION 2_: That the appropriate City officials are hereby authorized to execute an agreement with George Feld and Associates, Inc. for construction of the Tamarac Park Satellite Recreation Building. id (J Temp. Reso. #3525 1 1 2 3 4 5 7 B 9 10 11 12 SECTION 3: That this Resolution shall become effective immediately upon adoption. PASSED, ADOPTEED AND APPROVED thisv2%� Of , 1985. ATTEST: VX-.A" � - WWO-0031 ...I_ ____:. ASSISTANT CITY CLERK I HEREBY CERTIFY that I have approved the fo and correctness of this Resolu ion. CI RECORD OF COUNCIL VOTE MAYOR: KRAVITZ DISTRICT4: V/M STEIN DISTRICT3: CFM_STELZER y DISTRICT2: C/M MUNITZ DISTRICTI: C/M BERNSTEIN U'_► �Aso 6] =4 7 THE AMERICAN INSTITUTE OF ARCHITECTS AIA Document A107 Standard Form of Agreement Between Owner and Contractor Short Form Agreement for Small Construction Contracts Where the Basis of Payment is a STIPULATED SUM THIS DOCUMENT HAS IMPORTA..'T LEGAL CO•VSEQUEA'CES: CONSULTATION' WITH AN ATTORNEY 15 ENCOURACED W17H RESPECT TO ITS CO%'NLETION OR A400IfICA710N For other contracts the A►A issues Standard Forms of Ovvner-Contractor Agreements and Standard GenF•ra' Co-,dr: ors of the Contract for Construction for use in connection therev ith This document has been approved and endorsed by The Associated General Contractors of A-nvrica AGREEMENT made this 27th day of February Hundred and Eighty Five BETWEEN the Owner: CITY OF TAMARAC and the Contractor: GEORGE FELD AND ASSOCIATES, INC. the Project: RECREATION BUILDING FOR CITY OF TAMARAC the Architect: RICHARD RUBIN The Owner and Contractor agree aF set forth below. in the year Nineteen At.A DOCUMENT A107 • SMAU CONSUL C 710N Cf NTFACT * )ANUA%1 19-4 EDi' 1oti • AIA'_ • GIs-4 1Hi Akiii.'CR'; Or ARCHITEM, 173S A1w ViEK AVi r. v, :►rs-• %GION. D C 20:.., ARTICLE 1 THE WORK The'Contractor shall perform all the Work required by the Contract Documents for (Here insert the caption descriptive of the N'orh as used on other Contact Documents ) Labor and material to complete (turnkey) Recreation Building as per plans with specifications thereon consisting of Pages A-1, 2, 39 4, 5, 6, 7, 8; S-1, 2; E-1, 2; H.V.A.C, all dated 4/18/84, drawn by Richard S. Rubin, A.I.A. ARTICLE 2 TIME OF COMMENCEMENT AND COMPLETION The Work to be performed under this Contract shall be commenced within 10 days after date of this contract. and completed before or at end of 5 months (July 27, 1985) . ARTICLE 3 CONTRACT SUM The 0�xner shall pay the Contractor for the performance of the %York subject to additions and deducttrr.4 b, C^a-)Fc Order as pro-ided in the General Condrt:ons in cLrrren: funds, the Contract Sum of One Hundred Seventy— rSrarr heir thr lump sure ono rn:. ur.r: Vr-ctt w bo:F ac dewed - Nine Thousand, Nine Hundred Fifty and no/100 Dollars. ($179,950.00). Plus change Order No. 1: $16,000.00 to construct new sewer line as per plan by Williams, Hatfield and Stoner. TOTAL $195,950.00 AtA DOCUMIN't R,c` • 5.<.,.: CCtisTF,c;rp� CON'RACi • ;,.�,>`, 'ls`= :a Trams • Ar,4 . -; TH! a�'C:Ca.' t,rTIT;'TL O'r 1RC►i:TfCIS. 1-35 N[w YOR1, A\T . N\'• \':�c•rr1CT0ti D i ARTICLE 4 PROGRESS PAYMENTS Based upon Applications, or Payment submitted to the Kkil" by the Contractor and Certificates for Payment issued by the X}lif{j{ Ohl Owner shall make progress payments on account of the Contract Sum to the Contractor as follows: Upon bills submitted by Contractor and approved by him, City shall pay directly to Sub —Contractors and material suppliers, upon presentation of a partial Release of Lien from both the Contractor and vendor. Draws presented on application and Certificate for Payme nt forms will be paid to Contractor on the basis of 90% of work in place agreed between Contractor and City Building Department, less payments made to vendors. The bills from suppliers and sub -contractors can be presented when approved by Contractor. Contractor's application is to be presented monthly on the 20th. ARTICLE 5 FINAL PAYMENT The Owner shall make final payment 90 days after completion of the Work, provided the Lontract be then fully performed, subject to the pro%,isions of Article 16 of the General Conditions. ARTICLE 6 ENUMERATION OF CONTRACT DOCUMENTS The Contract Documents are as noted in Paragraph 7.1 of the General Conditions and are enumerated a, fol'o%+5 rlrs: beiON the Aperrhrmf Condauonr of the Conlract !Genera' Supplementa.�. and other Condtr,o^t DraKings Speu`i::':on, Addenea on:' accerirC Ahrrnatrs showing pagr or shevi numbers in all cases and dates where applicable See Article I AIA DOCUMP41 A10" • S• Aa'.: CONSTRUCTION CO%7RAC1 • JA%o41ZN 19-4 ED ;10], • A.la.¢ • 7H1 °.•,'!PICA!% INS11107E Or ARCHITECTS, 1735 NE11 MURK AVE. N'W 11AS-NC701. D.0 2t)(1x 3 I -4 GENERAL CONDITIONS ARTICLE 7 CONTRACT DOCUMENTS 7.1 The Contract Documents consist of this Agreement (which includes the General Conditions), Supplementary and other Conditions, the Drawings, the Specifications, all Addenda issued prior to the execution of this Agree- ment, all modifications, Change Orders, and written interpretations of the Contract Documents issued by the Architect. These form the Contract and what is required by any one shall be as binding as if required by all. The intention of the Contract Documents is to include all labor, materials, equipment and other items as provided in Paragraph 10.2 necessary for the proper execution and completion of the Work and the terms and conditions of payment therefor, and also to include all Work which may be reasonably inferable from the Contract Documents as being necessary to produce the intended results. 7.2 The Contract Documents shall be signed in not less than triplicate by the Owner and the Contractor. If either the Owner or the Contractor do not sign the. Drawings, Specifications, or any of the other Contract Documents, the Architect shall identify them. By executing the Con- tract, the Contractor represents that he has visited the site and familiarized himself with the local conditions under which the Work is to be performed. 7.3 The term Work as used in the Contract Documents includes all labor necessary to produce the construction required by the Contract Documents, and all materials and equipment incorporated or to be incorporated in such construction. ARTICLE 8 ARCHITECT 6.1 The Architect will provide general administration of the Contract and will be the Owner's repte>( ltative during construction and until issuance of the final Certi- ficate for Payment. 8.2 The Architect shall at all times have access to the Work wherever it is in preparation and progress. 8.3 The Architect will make periodic visits to the site to familiarize himself generally with the progress and quality of the %Mork and to determine in general if the work is proceeding in accordance with the Contract Documents. On the basis of his on -site observations as an architect, he will keep the Owner informed of the progress of the %'York, and will endeavor to guard the Owner against defects and deficiencies in the Work of the Contractor. The Architect will not be required to make exhaustive or continuous on -site inspections to check the quality or quantity of the Work. The Archi- tect will not be responsible for construction means, methods, techniques, sequences or procedures, or for safer%• precautions and program,. in connection with the %%ork. and he will not be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents. 8.4 Based on such observations and the Contractor's Applications for Payment, the Architect will determine the amounts owing to the Contractor and will Issue Cer- tificates for Payment in accordance with Article 16. 8.5 The Architect will be, in the first instance, the in- terpreter of the requirements of the Contract Documents. He will make decisions on all claims and disputes be- tween the Owner and the Contractor. All his decisions are subject to arbitration. 8.6 The Architect will have authority to reject Work which does not conform to the Contract Documents. ARTICLE 9 OWNER 9.1 The Owner shall furnish all surveys. 9.2 The Owner shall secure and pay for easements for permanent structures or permanent changes in existing facilities. 9.3 The Owner shall issue all instructions to the Con- tractor through theYSI) iLIM- Chief Building Of f icial ARTICLE 10 CONTRACTOR 10.1 The Contractor shall supen-ise and direct the work, using his best skill and attention. The Con- tractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. 10.2 Unless otherwise specifically noted, the Contractor shall provide and pay for all labor, materials, equipment, tools, construction equipment and machinen•. Hater, heat, utilities, transportation, and other facilities and services necessan• for the proper execution and comple- tion of the Work. 10.3 The Contractor shall at all times enforce strict discipline and good order among his employees, and shall not employ on the Work ant unfit persori or an - one not skilled in the task assigned to him. 10.4 The Contractor warrants to the Owner and the Architect that all materials and equipment into-porated in the Work will be ne,.+ unless otherwise spec fled. and that a!I work, will be of good qua!i*%, free f-o--: fau!ts and defects and in confo•rnance %%ilE the Contra:* D u- ments. All V%'ork not so conforming to the=e ste�d�. d4 may be considered defective. 103 The Contractor ,hal! pay all sales, conzu--.c r. usc- and other similar taxes required by la•+ and shall secu•e all permits. fees and licenses necessan for the execution of the Work. 10.6 The Contractor shall give all notices and cc^-p!1 with all lay,. s. ord-nances, rules, regulations, and orcers of and public authority bearing on the perfci-rr.z-ce of AIA DOCUMtNI AW • SMALL CONSIRUCTION CCNTi J C% • JANUARI 1�_4 FO;1:;1� AIAI� • 11974 THE A%iERICA% l%. S11TUT[ OF ARCHITECTS, 1735 NI%N yokc AVJ.. KM., f2-C. 2V-X 2 11-i the Work, and shall notify the Architect if the Drawings and Specifications are at variance therewith. 10.7 The Contractor shall be responsible for the acts and omissions of all his employees and all Subcon- tractors, their agents and employees and all other persons performing any of the Work under a contract with the Contractor. 10.8 The Contractor shall review, stamp with his ap- proval and submit all samples and shop drawings as directed for approval of the Architect for conformance with the design concept and with the information given in the Contract Documents, The Wort, shall be in ac- cordance with approved samples and shop drawings. 10.9 The Contractor at all times shall keep the premises free from accumulation of waste materials or rubbish caused by his operations. At the completion of the Work he shall remove all his waste materials and rubbish from and about the Project as well as his tools. construction equipment, machinerry, and surplus materials, and shall clean all glass surfaces and shall leave the Work "broom clean" or its equivalent, except as otherwise specified. 10.10 The Contractor shall indemnify and hold harmless the Owner and the Architect and their agents and em- ployees from and against all claims, damages, losses and expenses including attorrieys' fees arising out of or result- ing from the performance of the Work, provided thpt any such claim, damage, loss or expense (1) is attribut- able to bodily injury, sickness, disease or death, or to injun to or destruction of tangible property (other than the \Fork itself) including the loss of use resulting there- from, and (2) is caused in whole or in part by and negligent act or omission of the Contractor, any Sub- contractor, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable, regardless of .whether or not it is caused in part by a party indemnified hereunder. In any, and all claims against the Owner or the Architect or any, of their agents or employees by any employee of the Contractor, am" Subcontractor, anyone directly or indirecth employed by any of them or anyone for whose acts any of them map be liable, the indemnification obligation under this Para- graph 10.10 shall not be limited in any way by any limi- tation on the amount or type of damages, compensation or benefits pa%able by or for the Contractor or any Sub- contractor under workmen's compensation acts, dis- ability benefit acts or other employee benefit acts. The obligations of the Contractor under this Paragraph 10.10 shall not extend to the liability of the Architect, his agents or employees arising out of (1) the preparation or approval of maps, drawings, opinions. reports, sur- veys, Change Orders, designs or specifications, or (2) the giving of or the failure to give direction. or instructions b� the Architect, his agents or employees pro'. ided such giving, or failure to give is the primary cause of the injury or damage. ARTICLE 11 SUBCONTRACTS 11.1 A Subcontractor is a person who har a direct contract with the Contractor to perio-m a- % n= the Work at the cite. 11.2 Unless otherwise specified in the Contract Docu. ments or in the Instructions to Bidders, the Contractor, as soon as practicable after the award of the Contract, shall furnish to the Architect in writing a list of the name, of Subcontractors proposed for the principal por- tions of the Work. The Contractor shall not employ any Subcontractor to whom the Architect or the Owner may have a reasonable objection. The Contractor shall not be required to employ any Subcontractor to whom he has a reasonable objection. Contracts between the Con- tractor and the Subcontractor shall be in accordance with the terms of this Agreement and shall include the General Conditions of this Agreement insofar as applicable. ARTICLE 12 SEPARATE CONTRACTS 12.1 The Owner reserves the right to award other con- tracts in connection with other portions of the Project or other wort, on the site under these or similar Condi- tions of the Contract. 12.2 The Contractor shall afford other contractors rea- sonable opportunity for the introduction and storage of their materials and equipment and the execution of their work, and .shall properly connect and coordinate his Work with theirs. 12.3 Any costs caused by defective or ill-timed work shall be borne b� the party responsible therefor. ARTICLE 13 ROYALTIES AND PATENTS The Contractor shall pay all ro+alties and license fees. The Contractor shall defend all suits or claim: for in- fringement of any, patent rights and shall save the Owner harmless from loss on account thereof. ARTICLE 14 ARBITRATION All claims or disputes arising out of this Contr2c, or the breach thereof shall be decided b� arbitration in accord- ance %--Ah the Construction Industr Arbitration Rule= of the American Arbitration Association then obta" ril u^.- less the parties mutually agree otherwise. Notice of the demand for arbitration shall be filed in v.rtint the other part% to the Contract and v+,th the Ame•ica-. A-bi- iration Association and shell be made ,+ith.n 2 r@cs^nab!e time after the dispute has arisen. ARTICLE 15 TIME 15.1 Al! time Irmit_ stated in the are of the essence of the Contract. 15.2 If the Contractor is dela,ed at an, t;mt in tht progress of the Work b� changes ordered in tit %1 oil. b,. labor disputes, fire, unusual de!ax" in liar+ nr -tat on una%oidab!e casualties, causes beyond the Con�"actn-'s control, or by an, cause which the Architect ma, de- termine justifies the delay, then the Contract Time shal! be extcndt 2 by Change O-der fc- sucF Teas^n?`,!e !:m( as 1hE Arc':;tect ma'. deterrr„ne Air, DOCV%11%0 A107 . SMALL COtir�i t C;i(�ti (7tiTr~•.C' � jAti`"=r. C.; » . A), "r 7HE AMiPTJC 1 1\cT;1L'T1 Cie ARCF1'.`+ECI! 1-75 ti[M \OPA A\"E.. .• + \.+.5-"�C i'-'�. �^ �i `. 11 ARTICLE 16 PAYMENTS 16.1 'Payments shall be made as provided in Article 4 of this Agreement. 16.2 Payments may be withheld on account of (1) de- fective Work not remedied, (2) claims filed, (3) failure of the Contractor to make payments properly to Sub- contractors or for labor, materials, or equipment, (4) damage to another contractor, or (5) unsatisfactory prose- cution of the Work by the Contractor, 16.3 Final payment shall not be due until the Con- tractor has delivered to the Owner a complete release of all liens arising out of this Contract or receipts in full covering all labor, materials and equipment for which a lien could be filed, or a bond satisfactory to the Owner indemnifying him against any lien. 16.4 The making of final payment shall constitute a waiver of all claims by the Owner except those arising from 1,11 unsettled liens, (2) faulty or defective Work ap- pearing after Substantial Completion, (3) failure of the Work to comply with the requirements of the Contract Documents, or (4) terms of any special guarantees re- quired by the Contract Documents. The acceptance of final pz,mcnt shall a waiver of al! claims by the Contractor except those previously made in writ- ing and still unsettled. ARTICLE 17 PROTECTION OF PERSONS AND PROPERTY The Contractor shall be responsible for initiating. main- taining, and supervising all safety precautions and pro- grams in connection with the Work. He shall take all reasonable precautions for the safety of, and shall provide all reasonable protection to prevent damage, ,injury or loss to (1) all employees on the Work and other persons who ma,i be affected thereby, (2) all the Work and all materials and equipment to be incorporated therein, and (3, other property at the site or adjacent thereto. He shall comply with all applicable laws. ord;nances, rules. regulations and orders of any public authority having jurisdiction for the safety of persons or property or to protect them from damage, injury or loss. All damage or loss to am property caused in whole or in part by the Contractor, and- Subcontractor, any Sub - subcontractor or anyone directly or indirectly employed b� any of them, or b) anyone for whose acts any of them may be liable. shall be remedied b+ the Contractor, except damage or loss attributable to fault\ Drav:ings or Specifict'tions or to the acts or orn s, ions of the• Civmer or Architect or anyone employed by either of them or for v,hose acts either of them mz� be liable but v hich are no' attributable to the fault or neFljgence of the Contractor. ARTICLE 18 CONTRACTOR'S LIABILITY INSURANCE The Conti, -clot and each separate Contractor shall pur- chasr ane maintain such insurance as %Nis.l prc:ect him from claims under workmen's eumpensatior acts and other employee benefit acts, from claims for damages because of bodily injury, including death, and from claims for damages to property which may arise out of or result from the Contractor's operations under this Contract, whether such operations be by' himself or b� any Sub- contractor or anyone directly or indirectly employed by any of them. This insurance shall be written for not less than any limits of liability specifiedas part of this Con- tract, or required by law, whichever is the greater, and shall include contractual liability insurance as applicable to the Contractor's obligations under Paragraph 10,10. Certificates of such insurance shall be filed %with the Owner and each separate Contractor. ARTICLE 19 OWNER'S LIABILITY INSURANCE The Owner shall be responsible for purchzsinc and maintaining his own liability insurance and, a,. his op- tion, may maintain such insurance as will protect him against claims which may arise from operations under the Contract. ARTICLE 20 PROPERTY INSURANCE 20.4 The Owner and Contractor %%aive all righ's aF,7;nst each other for damages caused b% fire o• ot1-:(_. pe-:!s to the extent covered by insurance proti rded u^de! t":;s paragraph. The Contractor shall requ,re s:m:'z+z:�e•> b) Subcontractors and Sub -subcontractors ARTICLE 21 CHANCES IN' THE WORK 21.1 The Owner withou' invzlidat;r.c the C^n''zct order Chances in the Work con-ist:nc o` zd� de- letions, or modmcations, the Contract Sum and '-e C-­ tract Trine being adjusted according!,.. Ali sucl- Chi-.--F- in the \Fork shall be authorized b� written Cn,-nze O-dc- signed by the Owner o• the Architect as his du'� e ized agent. 21.2 The Contract Sum and the Contract lime rr.;� b ehanped only by Change Oder. 21.3 The cost or cred.. t- the O%vner fro^ a Cr. the \Work shall be detec-:-,:ned b� AIA MUMMY A107 - SIti'k:l C0N'5TRLTVO% Cn1.1kACT - t&.N'_!Ao1' 197Z 1DiTIC•N • A18A - Ir-: THt A,mFk1CA% 1%S7ITL'TF OF ARCHITECTS, 1735 ►.Eve VOR►. okkI , K.w.. N'ASHI%CION, D. C. Am3t J A ARTICLE 22 CORRECTION OF WORK The Contractor shall correct any Work that fails to con- form to the requirements of the Contract Documents where such failure to conform appears during the progress of the Work, and shall remedy any defects due to faulty materials, equipment or workmanship which appear within a period of one year from the Date of Substantial Completion of the Contract or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required by the Contract Documents. The provisions of this Article 22 apply to Work done by Subcontractors as well as to Work done by direct employees of the Contractor. ARTICLE 23 TERMINATION BY THE CONTRACTOR If the Architect fails to issue a Certificate of Payment for a period of thirty days through no fault of the Con- tractor, or if the Owner fails to make payment thereon for a period of thirty days, the Contractor may, upon seven days' written notice to the Owner and the Archi- tect, terminate the Contract and recover from the Owner payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, and construction equipment and machinery, including rea- sonable profit and damages. ARTICLE 24 TERMINATION BY THE OWNER If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents or fails to perform any provision of the Contract, the Owner may, after seven days' written notice to the Contractor and without prejudice to any, other remedy he may have, make good such deficiencies and may deduct the cost thereof from the payment then or thereafter due the Contractor or, at his option, may, terminate the Contract and take possession of the site and of all materials, equip- ment, tools, and construction equipment and machrner\ thereon owned by the Contractor and may finish the Work by whatever method he may deem expedient, and if the unpaid balance of the Contract Sum exceeds the expense of finishing the Work, such excess shall be paid to the Contractor, but if such expense exceeds such unpaid balance, the Contractor shall pay the difference to the Owner. ARTICLE 25 MISCELLANEOUS PROVISIONS Contractor is to furnish to City copies of executed sub —contracts and purchase orders for materials to be used as basis for payments. Contractor is to sign permit applications as licensed contractor. Contractor is to furnish a Certificate of Insurance showing City as co—insured for liability in the amount of $ 300 000•oo_, and obtain and furnish insurance certificates from all sub —contractors before payments are made. AIA DOCUMENT A10" • 5.1:,a Cii'. 'F..CT ti C("IMACi E::'TID•. !•.,:� •' '� i THE AMIIZIChs ISMT.ITt OF AP, M^(CT� 1735 •:E\\ 1'Or.r W C �, , IN WITLESS WHEREOF, the parties hereto have caused these presents to be executed on the day and year indicated below: signed, sealed and delivered in the presence of: ATTEST: y 7r. I TY MANAGER ATTEST: THE CITY OF TAMARAC By & �- MAYOR DATE Y_ CITY IANA ER DATE: Approved as to farm By A GEORGE FELD AND ASSOCIATES, INC. BY DATE ��7/OS